Handing Over of the Assets. The complete water supply system shall be handed over by the Contractor to the Employer at the end of trial run period. The system must be handed over in fully functional condition.
Handing Over of the Assets Sample Clauses
Related to Handing Over of the Assets
Transfer of the Property Any sale, lease, conveyance, assignment, pledge, encumbrance, or transfer of all or any part of the Property or any interest therein, voluntarily or involuntarily, whether by operation of law or otherwise, except: (i) sales or transfers of items of the Accessories which have become obsolete or worn beyond practical use and which have been replaced by adequate substitutes, owned by Mortgagor, having a value equal to or greater than the replaced items when new; and (ii) the grant, in the ordinary course of business, of a leasehold interest in a part of the Improvements to a tenant for occupancy, not containing a right or option to purchase and not in contravention of any provision of this Mortgage or of any other Loan Document. Mortgagee may, in its sole discretion, waive a default under this paragraph, but it shall have no obligation to do so, and any waiver may be conditioned upon such one or more of the following (if any) which Mortgagee may require: the grantee’s integrity, reputation, character, creditworthiness and management ability being satisfactory to Mortgagee in its sole judgment and grantee executing, prior to such sale or transfer, a written assumption agreement containing such terms as Mortgagee may require, a principal paydown on the Note, an increase in the rate of interest payable under the Note, a transfer fee, a modification of the term of the Note, and any other modification of the Loan Documents which Mortgagee may require. NOTICE - THE DEBT SECURED HEREBY IS SUBJECT TO CALL IN FULL IN THE EVENT OF SALE OR CONVEYANCE OF THE PROPERTY CONVEYED.
The Assets As used herein, the term “Assets” means all of the Company’s properties and assets, including its right, title and interest in, to and under the following, but, notwithstanding any provision herein to the contrary, excluding the Excluded Assets:
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Condition of the Business (a) Notwithstanding anything contained in this Agreement to the contrary, Purchaser acknowledges and agrees that Seller is not making any representations or warranties whatsoever, express or implied, beyond those expressly given by Seller in Article V hereof (as modified by the Seller Schedules as supplemented or amended), and Purchaser acknowledges and agrees that, except for the representations and warranties contained therein, the Purchased Assets and the Business are being transferred on a “where is” and, as to condition, “as is” basis. Any claims Purchaser may have for breach of representation or warranty shall be based solely on the representations and warranties of Seller set forth in Article V hereof (as modified by the Seller Schedules as supplemented or amended). Purchaser further represents that neither Seller nor any of its Affiliates nor any other Person has made any representation or warranty, express or implied, regarding Seller, the Purchased Assets, the Business or the transactions contemplated by this Agreement or as to the accuracy or completeness of any information not expressly set forth in this Agreement and neither Purchaser nor any of its Affiliates has relied on any such express or implied representation or warranty. Purchaser further agrees that none of Seller, any of its Affiliates or any other Person will have or be subject to any liability to Purchaser or any other Person resulting from the distribution to Purchaser or its representatives or Purchaser’s use of, any such information, including any confidential memoranda distributed on behalf of Seller relating to the Business or other publications or data room information provided to Purchaser or its representatives, or any other document or information in any form provided to Purchaser or its representatives in connection with the sale of the Business and the transactions contemplated hereby. Purchaser acknowledges that it has conducted to its satisfaction, its own independent investigation of the Business and, in making the determination to proceed with the transactions contemplated by this Agreement, Purchaser has relied on the results of its own independent investigation.
Sale and Purchase of the Assets Upon the terms and subject to the conditions set forth in this Agreement, at the Closing, the Seller shall sell, assign, transfer, convey and deliver to the Purchaser, and the Purchaser shall purchase and acquire from the Seller, free and clear of all Liens, all right, title and interest of the Seller in and to all of its properties, assets, Contracts and rights, of every kind and description and wherever located, related to, used in or intended for use in connection with the Business as currently conducted or currently contemplated to be conducted, other than the Excluded Assets (as defined below) (collectively, the “Purchased Assets”), including without limitation the following:
Purchase and Sale of the Assets (a) Purchase and Sale of the Assets. Subject to the terms and conditions of this Agreement and on the basis of the representations, warranties, covenants and agreements herein contained:
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
CHARACTERISTICS OF THE ACADEMY 10) The characteristics of the Academy set down in Section 1(6) of the Academies Act 2010, are that:
Operation of the Property During the Term, NAI shall operate the Property in a good and workmanlike manner and substantially in compliance with all Applicable Laws and will pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written notice given to NAI or BNPLC by any governmental authority, then for purposes of the preceding sentence, NAI shall be considered not to have maintained the Property "substantially in accordance with Applicable Laws" whether or not the noncompliance would be substantial in the absence of the notice.) During the Term, NAI shall not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. During the Term, to the extent that any of the following would, individually or in the aggregate, materially and adversely affect the value of the Property or NAI's use, occupancy or operations on the Property, NAI shall not, without BNPLC's prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. If (A) a change in the zoning or other Applicable Laws affecting the permitted use or development of the Property shall occur after the Base Rent Commencement Date that reduces the value of the Property, or (B) conditions or circumstances on or about the Property are discovered after the Base Rent Commencement Date (such as the presence of an endangered species) which substantially impede development and thereby reduce the value of the Property, and if after any such reduction under clause (A) or (B) preceding the Current AS IS Market Value of the Property is less than sixty percent (60%) of Stipulated Loss Value, then NAI shall pay BNPLC upon request the amount by which Current AS IS Market Value is less than sixty percent (60%) of Stipulated Loss Value, for application as a Qualified Prepayment. During the Term, NAI shall not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI shall not do any act whereby the market value of the Property may reasonably be expected to be materially lessened. During the Term, if NAI receives a written notice or claim from any federal, state or other governmental entity that the Property is not in compliance in any material respect with any Applicable Law, or that any action may be taken against the owner of the Property because the Property does not comply with Applicable Law, NAI shall promptly furnish a copy of such notice or claim to BNPLC. Notwithstanding the foregoing, NAI may in good faith, by appropriate proceedings, contest the validity and applicability of any Applicable Law with respect to the Property, and pending such contest NAI shall not be deemed in default hereunder because of the violation of such Applicable Law, if NAI diligently prosecutes such contest to completion in a manner reasonably satisfactory to BNPLC, and if NAI promptly causes the Property to comply with any such Applicable Law upon a final determination by a court of competent jurisdiction that the same is valid and applicable to the Property; provided, however, in any event such contest shall be concluded and the violation of such Applicable Law must be corrected by NAI and any claims asserted against BNPLC or the Property because of such violation must be paid by NAI, all prior to the earlier of (i) the date that any criminal prosecution is instituted or overtly threatened against BNPLC or any of its directors, officers or employees because of such violation, (ii) the date that any action is taken by any governmental authority against BNPLC or any property owned by BNPLC (including the Property) because of such violation, or (iii) a Designated Sale Date upon which, for any reason, NAI or an Affiliate of NAI or any Applicable Purchaser shall not purchase BNPLC's interest in the Property pursuant to the Purchase Agreement for a price to BNPLC (when taken together with any additional payments made by NAI pursuant to Paragraph 1(A)(2) of the Purchase Agreement, in the case of a purchase by an Applicable Purchaser) equal to the Break Even Price.
