Order Acceptance All orders are subject to acceptance only at Seller’s facility in Farmington, Connecticut. These Terms of Sale shall be deemed accepted by Buyer upon Seller’s receipt of Purchase Order from Buyer. No condition stated by Buyer shall be binding upon Seller if in conflict with, inconsistent with or in addition to the Terms of Sale, unless expressly accepted in a writing signed by Seller. In the event of conflict or differences in the terms or conditions of Buyer’s Purchase Order and the Terms of Sale herein, the Terms of Sale shall govern.
Product Acceptance Unless otherwise provided by mutual agreement of the Authorized User and the Contractor in the Authorized User Agreement, Authorized User(s) shall have sixty (60) days from the date of delivery to accept all Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Title or other property interest and risk of loss shall not pass from Contractor to the Authorized User until the Products have been accepted. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty
Engagement; Acceptance The Issuer engages Xxxxxxx Fixed Income Services LLC to act as the Asset Representations Reviewer for the Issuer. Xxxxxxx Fixed Income Services LLC accepts the engagement and agrees to perform the obligations of the Asset Representations Reviewer on the terms in this Agreement.
Procedure for Acceptance If Tenant wishes to exercise Tenant’s right of first refusal with respect to the space described in the First Refusal Notice, then within five (5) business days after delivery of the First Refusal Notice to Tenant (“Election Date”), Tenant shall deliver notice to Landlord of Tenant’s exercise of its right of first refusal with respect to the entire space described in the First Refusal Notice and on the First Refusal Economic Terms contained therein. Subject to the remaining provisions of this Section 1.4.2, if Tenant does not exercise its right of first refusal within the five (5) business day period (on all of the First Refusal Economic Terms), then Landlord shall be free to lease the space described in the First Refusal Notice to anyone to whom Landlord desires on any terms Landlord desires and Tenant’s right of first refusal with respect to the space identified in the First Refusal notice shall thereupon automatically terminate; provided, however, that if Landlord intends to enter into a lease upon First Refusal Economic Terms which are, in the aggregate, materially more favorable to a prospective tenant than those First Refusal Economic Terms proposed by Landlord in the First Refusal Notice to Tenant, then Landlord shall first deliver written notice to Tenant (“Second Chance Notice”) providing Tenant with the opportunity to lease the First Refusal Space on such more favorable First Refusal Economic Terms. For purposes hereof, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-five percent (95%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. Tenant’s failure to elect to lease the First Refusal Space upon such more favorable First Refusal Economic Terms by written notice to Landlord within five (5) business days after Tenant’s receipt of such Second Chance Notice from Landlord shall be deemed to constitute Tenant’s election not to lease such space upon such more favorable First Refusal Economic Terms, in which case Landlord shall be entitled to lease such space to any third (3rd) party on terms not materially more favorable to the third (3rd) party than those set forth in the Second Chance Notice; provided, however, that for purposes of the Second Chance Notice, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-eight percent (98%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. If Landlord does lease such First Refusal Space to a third (3rd) party tenant pursuant to the terms and conditions of this Section 1.4.2, Tenant shall have no further right to lease such First Refusal Space. If Landlord does not enter into a lease or leases all of the First Refusal Space identified by Landlord in such First Refusal Notice within three (3) months after the date Landlord first delivered such First Refusal Notice to Tenant, then Landlord shall submit to Tenant a new First Refusal Notice with respect to any such unleased First Refusal Space before Landlord may lease such space to another party, provided that no existing Superior Right holder wishes to lease such space in accordance with its Superior Rights in which event the foregoing procedures shall again apply following Tenant’s receipt of such new First Refusal Notice. Notwithstanding anything to the contrary contained herein, Tenant must elect to exercise its right of first refusal, if at all, with respect to all of the space comprising the First Refusal Space offered by Landlord to Tenant at any particular time, and Tenant may not elect to lease only a portion thereof or object to any of the First Refusal Economic Terms.
Time for Acceptance Unless the Optionee shall evidence his/her acceptance of this Option by execution of this Agreement within ten (10) days after its delivery to him/her, the Option and this Agreement shall be null and void.
CONDITIONS TO ACCEPTANCE OF SUBSCRIPTION The Company’s right to accept the subscription of the Subscriber is conditioned upon satisfaction of the following conditions precedent on or before the date the Company accepts such subscription:
Notice of Acceptance Notice of each Offeree’s intention to accept, in whole or in part, any Offer made shall be evidenced by a writing signed by such Offeree and delivered to the Company prior to the end of the 20-day period of such offer, setting forth such of the Offeree’s Basic Amount as such Offeree elects to purchase and, if such Offeree shall elect to purchase all of its Basic Amount, such Undersubscription Amount as such Offeree shall elect to purchase (the “Notice of Acceptance”). If the Basic Amounts subscribed for by all Offerees are less than the total Offered Securities, then each Offeree who has set forth Undersubscription Amounts in its Notice of Acceptance shall be entitled to purchase, in addition to the Basic Amounts subscribed for, all Undersubscription Amounts it has subscribed for; provided, however, that should the Undersubscription Amounts subscribed for exceed the difference between the Offered Securities and the Basic Amounts subscribed for (the “Available Undersubscription Amount”), each Offeree who has subscribed for any Undersubscription Amount shall be entitled to purchase only that portion of the Available Undersubscription Amount as the Undersubscription Amount subscribed for by such Offeree bears to the total Undersubscription Amounts subscribed for by all Offerees, subject to rounding by the Board of Directors to the extent it reasonably deems necessary.
Conditions of Offering; Acceptance and Purchases Any Offering will be subject to delivery of the Securities and their acceptance by us and any other Underwriters, may be subject to the approval of all legal matters by counsel and the satisfaction of other conditions, and may be made on the basis of reservation of Securities or an allotment against subscription. We will advise you by telecopy, telex or other form of written communication ("Written Communication", which term, in the case of any Offering described in Section 3(a) or 3(b) hereof, may include a prospectus or offering circular) of the particular method and supplementary terms and conditions (including, without limitation, the information as to prices and the offering date referred to in Section 3(c) hereof) of any Offering in which you are invited to participate. To the extent such supplementary terms and conditions are inconsistent with any provision herein, such terms and conditions shall supersede any such provision. Unless otherwise indicated in any such Written Communication, acceptances and other communications by you with respect to an Offering should be sent to the appropriate Syndicate Department of Xxxxxxx Xxxxx Barney Inc. We may close the subscription books at any time in our sole discretion without notice, and we reserve the right to reject any acceptance in whole or in part. Unless notified otherwise by us, Securities purchased by you shall be paid for on such date as we shall determine, on one day's prior notice to you, by wire transfer payable in immediately available funds to the order of Xxxxxxx Xxxxx Xxxxxx Inc., in an amount equal to the Public Offering Price (as hereinafter defined) or, if we shall so advise you, at such Public Offering Price less the Concession (as hereinafter defined). If Securities are purchased and paid for at such Public Offering Price, such Concession will be paid after the termination of the provisions of Section 3(c) hereof with respect to such Securities. Unless notified otherwise by us, payment for and delivery of Securities purchased by you shall be made through the facilities of The Depository Trust Company, if you are a member, unless you have otherwise notified us prior to the date specified in a Written Communication to you from us or, if you are not a member, settlement may be made through a correspondent who is a member pursuant to instructions which you will send to us prior to such specified date.
CERTIFICATE OF ACCEPTANCE Upon successful completion of the Technical Acceptance Process, the Buyer will, on or before the Delivery Date, sign and deliver to the Seller a certificate of acceptance in respect of the Aircraft in the form of Exhibit D (the “Certificate of Acceptance”).
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.
