Selection of Labor During the performance of this contract, the contractor shall not use convict labor for any purpose within the limits of a construction project on a Federal-aid highway unless it is labor performed by convicts who are on parole, supervised release, or probation. The term Federal-aid highway does not include roadways functionally classified as local roads or rural minor collectors.
NOTICE OF LABOR DISPUTES A. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information to the OWNER.
Hours of Labor Eight (8) hours labor constitutes a legal day's work. The Construction Manager shall forfeit, as a penalty to the State of California, twenty-five dollars ($25.00) for each worker employed in the execution of the Preconstruction Services Contract by the Construction Manager or any Subconsultant under the Construction Manager for each calendar day during which such worker is required or permitted to work more than eight (8) hours in any one calendar day and 40 hours in any one calendar week in violation of the provisions of the Labor Code, and in particular Sections 1810 to 1815 thereof, inclusive, except that work performed by employees in excess of eight (8) hours per day, and forty (40) hours during any one week, shall be permitted upon compensation for all hours worked in excess of eight (8) hours per day and forty (40) hours in any week, at not less than one and one-half times the basic rate of pay, as provided in Section 1815.
Absence of Labor Dispute No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, and the Company is not aware of any existing or imminent labor disturbance by the employees of any of its or any subsidiary’s principal suppliers, manufacturers, customers or contractors, which, in either case, would result in a Material Adverse Effect.
Day’s Labor Eight hours shall constitute a legal day's work for all classes of employees in this state except those engaged in farm and domestic service unless otherwise provided by law. No laborers, workmen or mechanics in the employ of the Contractor, Subcontractor or other person doing or contracting to do all or part of the work contemplated by the Contract shall be permitted or required to work more than eight hours in any one calendar day or more than five calendar days in any one week except in cases of extraordinary emergency including fire, flood or danger to life or property. “Extraordinary emergency” shall be deemed to include situations in which sufficient laborers, workers and mechanics cannot be employed to carry on public work expeditiously as a result of such restrictions upon the number of hours and days of labor and the immediate commencement or prosecution or completion without undue delay of the public work is necessary in the judgment of the NYS Commissioner of Labor for the preservation of the Contract site or for the protection of the life and limb of the persons using the Contract site.
Absence of Labor Disputes No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, which would reasonably be expected to result in a Material Adverse Effect.
Transfer of Labour If a halt to productive work occurs which is not the fault or the responsibility or the Company, the parties agree that employees can be relocated to other unaffected areas to continue productive work or to other sites if work is available. Provided that employees will continue to be paid in accordance with this Agreement during such a temporary transfer.
NOTICE TO BUYER OF LABOR DISPUTES Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
Sweatshop Labor If this Agreement provides for the laundering of apparel, garments or corresponding accessories, or for furnishing equipment, materials, or supplies other than for public works, this section is applicable. Contractor certifies that no apparel, garments or corresponding accessories, equipment, materials, or supplies furnished to the JBE under this Agreement have been laundered or produced in whole or in part by sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor or exploitation of children in sweatshop labor, or with the benefit of sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor or exploitation of children in sweatshop labor. Contractor adheres to the Sweatfree Code of Conduct as set forth on the California Department of Industrial Relations website located at xxx.xxx.xx.xxx, and PCC 6108. Contractor agrees to cooperate fully in providing reasonable access to Contractor’s records, documents, agents, and employees, and premises if reasonably required by authorized officials of the Department of Industrial Relations, or the Department of Justice to determine Contractor’s compliance with the requirements under this section and shall provide the same rights of access to the JBE.
Notice of Layoff The Employer shall make every reasonable effort under the circumstances to provide affected employees with at least fourteen (14) calendar days’ notice prior to the contemplated effective date of a layoff.
