Errors and Omissions All reports, files and other documents prepared and submitted by Contractor shall be complete and shall be carefully checked by the professional(s) identified by Contractor as project manager and key personnel attached hereto, prior to submission to the County. Contractor agrees that County review is discretionary and Contractor shall not assume that the County will discover errors and/or omissions. If the County discovers any errors or omissions prior to approving Contractor’s reports, files and other written documents, the reports, files or documents will be returned to Contractor for correction. Should the County or others discover errors or omissions in the reports, files or other written documents submitted by the Contractor after County approval thereof, County approval of Contractor’s reports, files or documents shall not be used as a defense by Contractor in any action between the County and Contractor, and the reports, files or documents will be returned to Contractor for correction.
Errors/Omissions The Engineer shall make revisions to the work authorized in this contract which are necessary to correct errors or omissions appearing therein, when required to do so by the State. No additional compensation shall be paid for this work.
ERRORS AND OMISSIONS RELATED TO DATA 11.1.0 Board errors and retroactive adjustments shall be the responsibility of the Board.
Technology Errors and Omissions The Contractor shall maintain during the term of the Contract Technology Errors and Omissions Insurance for claims for damages arising from computer related services including, but not limited to, the following: consulting, data processing, programming, system integration, software development, installation, distribution or maintenance, systems analysis or design, training, staffing or other support services, any electronic equipment, computer software developed, manufactured, distributed, licensed, marketed or sold. If the policy is written on a claims made basis, Contractor must provide to OGS proof that the policy provides the option to purchase an Extended Reporting Period (“tail coverage”) providing coverage for no less than one (1) year after work is completed in the event that coverage is cancelled or not renewed. This requirement applies to both primary and excess liability policies, as applicable.
Professional Liability (Errors and Omissions) For consultant contracts, insurance appropriate to Consultant’s profession, with limit no less than $1,000,000 per occurrence or claim, $2,000,000 aggregate. If Contractor maintains broader coverage and/or higher limits than the minimums shown above, City requires and shall be entitled to the broader coverage and/or the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to City.
Professional Liability (Errors & Omissions Insurance with limits of not less than $1,000,000 each occurrence, $2,000,000 aggregate. Such insurance will cover all professional services rendered by or on behalf of PROVIDER and its subcontractors under this Agreement. Renewal policies written on a claims- made basis will maintain the same retroactive date as in effect at the inception of this Agreement. If coverage is written on a claims-made basis, PROVIDER agrees to purchase an Extended Reporting Period Endorsement, effective for two (2) full years after the expiration or cancellation of the policy. No professional liability policy written on an occurrence form will include a sunset or similar clause that limits coverage unless such clause provides coverage for at least three (3) years after the expiration of cancellation of this Agreement.
Errors and Omissions Insurance Errors and Omissions Insurance to be maintained by the Servicer in accordance with Section 3.13.
Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.
Professional Liability (Errors and Omissions) Insurance Limits shall not be less than the following:
Delays or Omissions No delay or omission to exercise any right, power or remedy accruing to any party under this Agreement, upon any breach or default of any other party under this Agreement, shall impair any such right, power or remedy of such non-breaching or non-defaulting party nor shall it be construed to be a waiver of any such breach or default, or an acquiescence therein, or of or in any similar breach or default thereafter occurring; nor shall any waiver of any single breach or default be deemed a waiver of any other breach or default theretofore or thereafter occurring. Any waiver, permit, consent or approval of any kind or character on the part of any party of any breach or default under this Agreement, or any waiver on the part of any party of any provisions or conditions of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. All remedies, either under this Agreement or by law or otherwise afforded to any party, shall be cumulative and not alternative.
