District’s Rights. The District reserves the right to cancel this Agreement, when it is determined by the District that the facilities are needed for school purposes. DATED this day of , 20 .
District’s Rights. Section 1: The Board, on its own behalf and on behalf of the electors of the school district, hereby retains and reserves unto itself without limitation, all powers, rights, authority, duties and responsibilities conferred upon and vested in it by all applicable State and Federal laws as well as the terms and conditions of this Agreement. Such rights, duties, etc., shall include, by way of illustration and not by way of limitation, the right to:
District’s Rights. The District:
District’s Rights. It is further understood and agreed by Licensee that District's rights to Premises are paramount to this License. Licensee shall in no way interfere with District's right to use, access or possess the Premises.
District’s Rights. If Tenant (or any contractor or subcontractor, as applicable) does not cause to be recorded the bond described in California Civil Code section 8000 et seq. or otherwise protect the Premises and Improvements under any alternative or successor statute, and a final judgment has been rendered against Tenant by a court of competent jurisdiction for the foreclosure of a mechanic’s, materialman’s, contractor’s or subcontractor’s lien claim, and if Xxxxxx fails to stay the execution of judgment by lawful means or to pay the judgment, District shall have the right, but not the duty to pay or otherwise discharge, stay or prevent the execution of any such judgment or lien or both. Upon any such payment by District, Tenant shall immediately upon receipt of written request therefor by District, reimburse District for all sums paid by District under this paragraph together with all District’s reasonable attorney’s fees and costs, plus interest at the Interest Rate from the date of payment until the date of reimbursement.
District’s Rights. 8-1 Retention of District Prerogatives: Except as expressly modified or restricted by a specific provision of the Agreement, all statutory and inherent managerial rights, prerogatives and functions are retained and vested exclusively in the Board of Trustees of the Xxxxxxxxx County School District, including, but not limited to, the rights, in accordance with its sole and exclusive judgment and discretion, to the following:
District’s Rights. The District reserves the right to cancel this Agreement, when it is determined by the District that the facilities are needed for school purposes. DATED this day of , 20 . Bainville K-12 Schools: Requesting Organization or Individual: By By Address Phone
District’s Rights. The District reserves the right to perform work related to the Project with the District’s own forces, and to award separate contracts in connection with other portions of the Project or other construction or operations on the Site. Upon the election to perform work with its own forces or by separate contracts, the District shall notify the Contractor. If the Contractor claims that delay or additional cost is involved because of such action by the District, the Contractor shall make such Claim as provided elsewhere in the Contract Documents.
District’s Rights. The District may occupy or use any completed or partially completed portion of the Work at any stage. The District and the Contractor shall agree in writing to the responsibilities assigned to each of them for payments, security, maintenance, heat, utilities, damage to the Work, insurance, the period for correction of the Work, and the commencement of warranties required by the Contract Documents. When the Contractor considers a portion complete, the Contractor shall prepare and submit a Punch List to the District as provided under paragraph 9.7.1. It is understood and agreed that the District shall have the right to occupy the building or use the improvement contemplated by the Contract prior to the completion of the entire work, and that such occupancy or use shall not operate as an acceptance of any part of the work, nor shall the Contractor be entitled to, or make demand for, additional compensation or extension of time because of such occupancy In case that the Contractor has not completed the work and the contract time, including authorized time extensions, has expired, the District reserves the right to occupy any portion of the Work at any time before completion and while work is in progress. In the event of such occupancy, the Contractor shall provide, without additional cost to the District, suitable protection by means of fencing, barriers, posted signs or other method as required to prevent persons other than those directly connected with the Work from entering remaining areas where continuing Work is being conducted, vehicles are operating, or materials are stored. Occupancy by the District prior to final acceptance shall not be deemed to constitute a waiver of existing claims in behalf of the District or Contractor against each other. If the Contractor fails to complete all of the project in the time frame agreed upon, including any approved time extensions, the Contractor shall not enter into any occupied areas to complete the Work until after those areas are vacated each day by district personnel and or students. The metered cost of electricity, water, fuel, etc., for the occupied portion and the cost of operating the heating and air conditioning systems for the occupied portion will be borne by the Contractor until final completion. Use and occupancy by the District prior to final acceptance shall not relieve the Contractor of his responsibility to provide and maintain all insurance and bonds required of the Contractor under the contract u...
District’s Rights. 4.1 District retains, solely and exclusively, all the rights, powers, and authority exercised or held prior to the execution of this Agreement, except as expressly limited by a specific provision of this Agreement. Without limiting the generality of the foregoing, the rights, powers and authority retained solely and exclusively by the District and not abridged herein include, but are not limited to, the following: to manage and direct its business and personnel; to manage, control and determine the mission of its departments, building facilities and operations; to create, change, combine or abolish jobs, departments and facilities in whole or in part; to sub-contract or discontinue work for economic or operational reasons; to direct the work force; to increase or decrease the work force and determine the number of employees needed; to hire, transfer, promote and maintain the discipline and efficiency of its employees; to establish work standards, schedules of operation and reasonable work load; to specify or assign work requirements and require overtime; to schedule working hours and shifts; to determine the type and scope of work to be performed and the services to be provided; to determine the methods, processes, means and places of providing services, and to take whatever action necessary to prepare for or operate in an emergency.
