DELAYS AND SUSPENSIONS Sample Clauses

DELAYS AND SUSPENSIONS. 32.1. The County may direct the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the Contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Contractor.
Sample 1Sample 2Sample 3See All (17)
AutoNDA by SimpleDocs
DELAYS AND SUSPENSIONS. Company may delay or suspend all or any part of this Agreement by providing written notice to Provider. Provider's obligations to Company under this Agreement will remain in full force and effect despite the delay or suspension of this Agreement under this Section. If Company suspends this Agreement, Provider shall be entitled to compensation in accordance with the terms of this Agreement up to the date of suspension; provided, however, Company’s liability to Provider shall in no case exceed the compensation payable to Provider pursuant to this Agreement, as appropriately adjusted and without duplication of payment.
Sample 1Sample 2
DELAYS AND SUSPENSIONS. The Company may suspend or delay the effectiveness of the Registration Statement for one or more reasonable periods of time (but not exceeding thirty (30) days in the aggregate during any twelve (12) month period), if (a) the Company determines, in its reasonable judgment, that such registration or offering would interfere with any financing, acquisition, corporate reorganization or other material transaction involving the Company or any of its Affiliates or would require premature disclosure thereof and (b) gives Stockholder at least two (2) Business Days prior written notice of such delay or suspension. Nothing contained in this Section 8, however, affects the Company's obligations under Section 3.5, except as provided herein.
Sample 1Sample 2
DELAYS AND SUSPENSIONS. The provisions in this Section 5.3 are intended to apply to situations involving the ongoing, uninterrupted Manufacture of Sarepta Drug Products once the Lead DMD Product Launch has occurred. [**]
Sample 1
DELAYS AND SUSPENSIONS. The provisions in this Section 3.5 are intended to apply to situations involving the ongoing, uninterrupted Manufacture of BridgeBio Products, including orders for [***] In the event of delays in approval or commercial launch or suspension of production after initial launch (for reasons other than the negligence (or more culpable conduct) of Catalent or a breach of this Agreement by Catalent) and if (for reasons other than the negligence (or more culpable conduct) of Catalent or a breach of this Agreement by Catalent) BridgeBio is unable to increase orders for the Manufacture of other BridgeBio Products in the Dedicated Clean Room Suite, BridgeBio shall pay to Catalent the Minimum Annual Threshold (as the same may be offset by work conducted in such suites pursuant to a Scope of Work or Purchase Orders) for as long as the Manufacture of the BridgeBio Product is delayed or suspended, and there shall be no additional payments or costs arising from BridgeBio’s provision of the Rolling Forecast (including the binding portion thereof) or actual Purchase Orders placed other than for the Manufacture of Batches which have commenced and for the non-cancelable orders of Raw Materials.
Sample 1
DELAYS AND SUSPENSIONS. 19.1. The County may direct the Solar Power Provider, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the Solar Power Provider's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Solar Power Provider.
Sample 1
DELAYS AND SUSPENSIONS. 33.1. The County may direct the contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time deemed appropriate for the convenience of the County. The County will extend the contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work, and is at least as long as the delay imposed by the County. The County may further amend the contract by mutual agreement for any increase in the cost of performance of the contract (excluding profit) resulting solely from the delay or suspension of the contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the contractor.
Sample 1
AutoNDA by SimpleDocs
DELAYS AND SUSPENSIONS. 21.1 AlexRenew may direct the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this Contract for the period of time deemed appropriate for the convenience of AlexRenew. AlexRenew will extend the Contractor's time of completion by a period of time that in the discretion of the Purchasing Agent is reasonably suited for completion of work. AlexRenew may further amend the Contract by mutual agreement for any increase in the cost of performance of the Contract (excluding profit) resulting solely from the delay or suspension of the Contract. No adjustment shall be made under this clause for any delay or interruption resulting from any other cause, including the fault or negligence of the Contractor.
Sample 1
DELAYS AND SUSPENSIONS. Notwithstanding the foregoing, the Company may delay filing a registration statement, and may withhold efforts to cause the registration statement to become effective, if the Board of Directors of the Company determines in good faith that such registration might (i) interfere with or affect the negotiation or completion of any transaction that is being contemplated by the Company (whether or not a final decision has been made to undertake such transaction) at the time the right to delay is exercised, or (ii) involve initial or continuing disclosure obligations that might not be in the best interest of the Company's stockholders. If, after a registration statement becomes effective, the Company advises the Holder that the Company considers it appropriate for the registration statement to be amended, the Holder shall suspend any further sales of its registered Shares until the Company advises them that the registration statement has been so amended.
Sample 1

Related to DELAYS AND SUSPENSIONS

  • Debarment and Suspension A. The Contractor certifies by entering into this Contract that neither it nor its principals nor any of its subcontractors are presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State of Indiana. The term “principal” for purposes of this Contract means an officer, director, owner, partner, key employee or other person with primary management or supervisory responsibilities, or a person who has a critical influence on or substantive control over the operations of the Contractor.

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • Cancellation and Suspension Section 5.01. This Agreement shall come into force and effect on the date upon which the Loan Agreement becomes effective.

  • CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals:

  • Service Suspension 8.1 By giving reasonable notice to you, or if this is not practicable, such notice as is reasonably practicable in the circumstances, we may suspend the Service (or any part of the Service) for reasons to include but not limited to:

  • No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.

  • Post Suspension 1. Without prejudice to the procedures in Article 190 (Examination of the Benefit Suspension Level), if the Party complained against considers that it has eliminated the non-conformity that the Panel has found, it may provide written notice to the complaining Party with a description of how non-conformity has been removed. If the complaining Party has disagreement, it may refer the matter to the original Panel within 60 days after receipt of such written notice. Otherwise, the complaining Party shall promptly stop the suspension of benefits. 2. The Panel shall release its report within 60 days after the referral of the matter. If the Panel concludes that the Party complained against has eliminated the non-conformity, the complaining Party shall promptly stop the suspension of benefits.

  • Term Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms.

  • Dismissal and Suspension (a) The Employer may dismiss or suspend for just cause any employee who has completed their probationary period. Notice of dismissal or suspension will be in writing and will set forth the reasons for dismissal or suspension and an employee will have the right to have a xxxxxxx present, providing that this does not result in an undue delay of the appropriate action being taken. A copy of the written notice of suspension or dismissal will be forwarded to the President of the Union or the designated staff representative within five working days.

  • No Suspension, Etc Trading in the Company’s Common Stock shall not have been suspended by the Commission or the OTC Bulletin Board (except for any suspension of trading of limited duration agreed to by the Company, which suspension shall be terminated prior to the Closing), and, at any time prior to the Closing Date, trading in securities generally as reported by Bloomberg Financial Markets (“Bloomberg”) shall not have been suspended or limited, or minimum prices shall not have been established on securities whose trades are reported by Bloomberg, or on the New York Stock Exchange, nor shall a banking moratorium have been declared either by the United States or New York State authorities, nor shall there have occurred any material outbreak or escalation of hostilities or other national or international calamity or crisis of such magnitude in its effect on, or any material adverse change in any financial market which, in each case, in the judgment of such Purchaser, makes it impracticable or inadvisable to purchase the Securities to be issued as of the Closing.

Time is Money Join Law Insider Premium to draft better contracts faster.