Delay by the Customer Sample Clauses

Delay by the Customer. The Customer shall take delivery of the Goods and Services on the Scheduled Delivery Date and shall not delay delivery of the Goods or Services without Seller’s consent. If the Customer delays delivery of Goods or Services, such delay may give rise to a price increase by Seller for the Goods or Services prior to shipment of Goods or rendering of Services, and the Customer agrees to pay all costs associated with such delay, including without limit any storage expenses, and payments are to be made by the Customer as though shipment had been made or Services performed as scheduled. Title and risk of loss for Equipment placed in storage will pass to the Customer upon placement of the Equipment into storage and the warranty will start on that date. If the Customer delays delivery of the Goods or Services for a period of more than ninety (90) days beyond the Scheduled Delivery Date, then Seller may cancel the Order by written notice to the Customer. Upon any cancellation pursuant to this provision, Seller will be entitled, as a minimum, to all costs actually incurred up to the time of cancellation, plus a fair and reasonable pro rata profit on such cost. Seller will prepare a cancellation notice and an invoice containing the applicable cancellation charges for submission to the Customer, which amounts will be due and payable upon receipt.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Delay by the Customer. 16.1. If performance of the Flight Schedule or any part thereof is prevented or delayed by the Customer, its servants or agents or any passenger arriving later than 30 minutes prior to the scheduled Departure Time, the Carrier may, at its sole discretion and without any liability whatsoever and to whosoever, either depart as scheduled or charge demurrage against the Customer at a daily rate equivalent to FIVE Flight Hours at the current Charter Price.
Sample 1

Related to Delay by the Customer

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Delivery by the Company At the Closing, the Company shall register the Shares in the name of the Employee. If the Shares are certificated, any certificates relating to the Shares shall be held by the Secretary of the Company or his or her designee on behalf of the Employee.

  • Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.

  • Actions by the Company (a) The Company hereby approves of and consents to the Offer and represents and warrants that the Board of Directors at a meeting duly called and held has by a unanimous vote duly adopted resolutions (i) approving this Agreement, the Offer and the Merger, determining that the Merger is advisable and that the terms of the Offer and Merger are fair to, and in the best interests of, the Company's stockholders and recommending that the Company's stockholders accept the Offer and tender all of their shares of Common Stock to Merger Sub and approve this Agreement and the transactions contemplated hereby, including the Offer and the Merger, (ii) taking all action necessary to render the restrictions set forth in Section 203 of the Delaware General Corporation Law, as amended (the "DGCL"), inapplicable to the Offer, the Merger, this ---- Agreement, the Tender Agreement and any of the transactions contemplated hereby and thereby and (iii) electing, to the extent permitted by law, not to be subject to any "moratorium," "control share acquisition," "business combination," "fair price" or other form of corporate anti-takeover laws and regulations of any jurisdiction that may purport to be applicable to this Agreement or the Tender Agreement. The Company further represents and warrants that the Board of Directors has received the opinion of Credit Suisse First Boston Corporation (the "Financial Advisor") to the effect that, as of the date ----------------- of this Agreement, the Offer Consideration to be received in the Offer and the Merger by the holders of Common Stock is fair, from a financial point of view, to such holders (other than Purchaser and its affiliates) (the "Fairness -------- Opinion"). Subject to the last sentence of this Section 1.3(a), the Company ------- -------------- hereby consents to the inclusion in the Offer Documents of the recommendation of the Board of Directors described in the first sentence of this Section 1.3(a). -------------- The Company hereby represents and warrants that it has been authorized by the Financial Advisor to permit the inclusion of the Fairness Opinion and references thereto, subject to prior review and consent by the Financial Advisor (such consent not to be unreasonably withheld) in the Offer Documents, the Schedule 14D-9 (as defined in Section 1.3(b)) and the Proxy Statement (as defined in Section 8.2(b)), if -------------- -------------- applicable. The Company has been advised by each of its directors and executive officers that each such person intends to tender all shares of Common Stock owned by such person pursuant to the Offer, except to the extent of any restrictions created by Section 16(b) of the Exchange Act. The Board of Directors shall not withdraw, modify or amend its recommendations described above in a manner adverse to Purchaser (or announce publicly its intention to do so), except that the Board of Directors shall be permitted to withdraw, amend or modify its recommendation (or publicly announce its intention to do so) of this Agreement or the Merger in a manner adverse to Purchaser or approve or recommend or enter into an agreement with respect to a Superior Proposal (as defined in Section 8.8) if the Company has complied with the terms of Section 8.8 and ----------- ----------- Section 10.1(e). --------------

  • Default by the Company If the Company shall fail at Closing Time or at the Date of Delivery to sell the number of Securities that it is obligated to sell hereunder, then this Agreement shall terminate without any liability on the part of any nondefaulting party; provided, however, that the provisions of Sections 1, 4, 6, 7 and 8 shall remain in full force and effect. No action taken pursuant to this Section shall relieve the Company from liability, if any, in respect of such default.

  • Termination by the Company This Agreement may be terminated by the Company at any time prior to the Effective Time:

  • Notice by the Company The Company shall give prompt written notice to a Responsible Officer of the Trustee at the Principal Office of the Trustee of any fact known to the Company that would prohibit the making of any payment of monies to or by the Trustee in respect of the Debentures pursuant to the provisions of this Article XV. Notwithstanding the provisions of this Article XV or any other provision of this Indenture, the Trustee shall not be charged with knowledge of the existence of any facts that would prohibit the making of any payment of monies to or by the Trustee in respect of the Debentures pursuant to the provisions of this Article XV, unless and until a Responsible Officer of the Trustee at the Principal Office of the Trustee shall have received written notice thereof from the Company or a holder or holders of Senior Indebtedness or from any trustee therefor; and before the receipt of any such written notice, the Trustee, subject to the provisions of Article VI of this Indenture, shall be entitled in all respects to assume that no such facts exist; provided, however, that if the Trustee shall not have received the notice provided for in this Section at least 2 Business Days prior to the date upon which by the terms hereof any money may become payable for any purpose (including, without limitation, the payment of the principal of (or premium, if any) or interest on any Debenture), then, anything herein contained to the contrary notwithstanding, the Trustee shall have full power and authority to receive such money and to apply the same to the purposes for which they were received, and shall not be affected by any notice to the contrary that may be received by it within 2 Business Days prior to such date. The Trustee, subject to the provisions of Article VI of this Indenture, shall be entitled to conclusively rely on the delivery to it of a written notice by a Person representing himself to be a holder of Senior Indebtedness (or a trustee or representative on behalf of such holder), to establish that such notice has been given by a holder of such Senior Indebtedness or a trustee or representative on behalf of any such holder or holders. In the event that the Trustee determines in good faith that further evidence is required with respect to the right of any Person as a holder of such Senior Indebtedness to participate in any payment or distribution pursuant to this Article XV, the Trustee may request such Person to furnish evidence to the reasonable satisfaction of the Trustee as to the amount of such Senior Indebtedness held by such Person, the extent to which such Person is entitled to participate in such payment or distribution and any other facts pertinent to the rights of such Person under this Article XV, and, if such evidence is not furnished, the Trustee may defer any payment to such Person pending judicial determination as to the right of such Person to receive such payment.

  • Release by the Company (a) The Company on behalf of itself, its agents, successors, affiliated entities and assigns, in consideration for the Executive’s execution and delivery of this Release, hereby forever releases and discharges the Executive, and his agents, heirs, successors, assigns, executors and administrators, from any and all known and unknown causes of action, actions, judgments, liens, indebtedness, damages, losses, claims, liabilities, and demands of whatsoever kind and character in any manner whatsoever arising on or prior to the date of this Release, including but not limited to (i) any claim for breach of contract, breach of implied covenant, breach of oral or written promise, defamation, interference with contract relations or prospective economic advantage, negligence, misrepresentation; (ii) any and all liability that was or may have been alleged against or imputed to the Executive by the Company or by anyone acting on its behalf; (iii) any punitive, compensatory or liquidated damages; and (iv) all rights to and claims for attorneys’ fees and costs except as otherwise provided in his amended and restated employment agreement with the Company dated December [__], 2008 (the “Employment Agreement”).

  • Acceptance by the Company It is understood that this subscription is not binding on the Company until the Company accepts it, which acceptance is at the sole discretion of the Company and shall be noted by execution of this Agreement by the Company where indicated.

  • Cooperation by the Company If any Shareholder shall transfer any Registrable Securities pursuant to Rule 144, the Company shall cooperate, to the extent commercially reasonable, with such Shareholder and shall provide to such Shareholder such information as such Shareholder shall reasonably request.

Time is Money Join Law Insider Premium to draft better contracts faster.