Defects in Workmanship - The warranty will cover defects in workmanship for all labor and services provided by the MRP Vendor for this stabilization project.
Workmanship means a good and high quality and standard of delivery in connection with the Services performed; “Works” means the supply of Goods and the provision of Services to the Customer as per each Statement of Work;
Defects means any part of the Works not completed in accordance with the Contract, or completed with deficiencies and flaws and includes deficiencies, flaws, etc. developed during the execution of Works and during the Defect Liability Period.
Latent Defects means such defects caused by faulty designs, material or work-man- ship which cannot be detected during inspection, testing etc, based on the technology available for carrying out such tests.
Contract Specifications means the principal trading terms in CFD (for example Spread, Swaps, Lot Size, Initial Margin, Necessary Margin, Hedged Margin, the minimum level for placing Stop Loss, Take Profit and Limit Orders, financing charges, charges etc) for each type of CFD as determined by the Company from time to time.
Defective Work means (a) Work that is unsatisfactory, deficient or damaged, does not conform to the Contract Documents, or does not meet the requirements of any inspection, test or approval, or (b) Work associated with punch list items that the Contractor fails to complete within a reasonable time after issuance of the punch list by the Project Manager.
Latent Defect means a defect, inherently lying within the material or arising out of design deficiency, which do not manifest themselves and/or was not reasonably discoverable during Defect Liability period.
Contractor Materials means Materials owned or developed prior to the provision of the Work, or developed by Contractor independently from the provision of the Work and without use of the Court Materials or Confidential Information.
Nonconformance as used in this clause means a condition of any hardware, software, material, or service/workmanship in which one or more characteristics do not conform to requirements.
Manufacturer’s Warranty means the warranty supplied from time to time by the manufacturer of the Goods as at the date of the acceptance of the Statement of Work; “PPSA” means the Personal Property Securities Xxx 0000; “Price” means the amount specified within each Statement of Work (subject to any Variation) or as otherwise specified from the Company to the Customer representing the cost for the Works; “Related Work” means any additional building, carpentry, painting, plastering, plumbing or other work or other trades that the Customer requires, which are not to be carried out by the Company; “Services” means the services provided by the Company to the Customer as part of the Works, which may include without limitation the installation of Goods; “Services Delay Charge” means the services delay charge (if any) set out in the Statement of Work; “Services Interruption Event” means any interruption to a Works caused by; a Force Majeure Event, the Customer’s failure to carry out or perform any obligation required of it under this agreement which in the sole opinion of the Company does or may cause a delay in the Works and any other matter which in the reasonable opinion of the Company will cause an interruption or delay in the performance of the Works; “Statement of Work” means the details outlining the provision of the Works, which statement can be delivered verbally or in writing (including email) and may include (where applicable) an estimate or quotation (as specifically expressed as the case) of costs; “Variation” means a change in the Statement of Work including the specifications, scope, time of supply, price or scale of the Works and such variation shall form part of this agreement; “Workmanship” means a good and high quality and standard of delivery in connection with the Services performed; “Works” means the supply of Goods and the provision of Services to the Customer as per each Statement of Work;
Product Warranty has the meaning set forth in Section 9.3.
Adulterated Specimen means a specimen that contains a substance that is not expected to be present in oral fluid, or contains a substance expected to be present but is at a concentration so high that it is not consistent with oral fluid.
Technical Specifications means the detailed requirements for the Work furnished by the Architect and set forth in Book 3 of the Contract Documents.
Product Specifications means those Manufacturing, performance, quality - control release, and Fill/Finish specifications for Drug Substance or Licensed Product in the Territory, which are initially as set forth in the applicable Regulatory Approval for a Licensed Product, as such specifications may be amended from time to time pursuant to the terms of this Agreement.
Specifications means the Specifications of the Works included in the Contract and any modification or addition made or approved by the Project Manager.
Functional Specifications means the descriptions of features and functions of the Application as expressly set forth in Quote.
Contractor Software means software which is proprietary to the Contractor, including software which is or will be used by the Contractor for the purposes of providing the Services.
Contract Work means everything required to be furnished and done by the Contractor by any one or more of the parts of the Contract referred to in Article 1, except Extra Work as hereinafter defined.
Service Specifications means the following documents, as applicable to the Services under Your order:
Custom Materials means Materials developed by the Supplier at the Procuring Entity's expense under the Contract and identified as such in Appendix 5 of the Contract Agreement and such other Materials as the parties may agree in writing to be Custom Materials. Custom Materials includes Materials created from Standard Materials.
Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;
Work/ works means work / works to be executed in accordance with the contract.
Goods Specification any specification for the Goods including any relevant plans or drawings, that is agreed in writing by the Reseller and Voip-Unlimited.
Nonconformity or “Nonconformities” means any failure or failures of the Software to conform to the requirements of this Contract, including any applicable Documentation.
technical specification means a document that prescribes technical requirements to be fulfilled by a product, process or service;
Minor Technical Irregularities means anything in the proposal that does not affect the price quality and quantity or any other mandatory requirement.
Web Site Accessibility Standards/Specifications means standards contained in Title 1 Texas Administrative Code Chapter 206.