Contractor's Claims. 8.1.1 If the Contractor considers himself to be entitled to any extension of the Time for Completion and/or any additional payment, under any Clause of these Conditions or otherwise in connection with the Contract, the Contractor shall give notice to the Project Manager, describing the event or circumstance giving rise to the claim. The notice shall be given as soon as practicable, and not later than 28 days after the Contractor became aware, or should have become aware, of the event or circumstance.
Contractor's Claims. If the Contractor considers himself to be entitled to any extension of the Time for Completion and/or any additional payment, under any clause of these Conditions or otherwise in connection with the Contract the Contractor shall give notice to the Engineer, describing the event or circumstances giving rise to the claim together with an explanation of the basis of its claim. The notice shall be given as soon as practicable, and not later than 28 days after the Contractor became aware, or should have become aware, of the event or circumstance. If the Contractor fails to give notice of a claim within such period of 28 days, the Time for Completion shall not be extended, the Contractor shall not be entitled to additional payment, and the Employer shall be discharged from all liability in connection with the claim. Otherwise, the following provisions of this sub-clause shall apply. The Contractor shall also submit any other notices which are required by the Contract, and supporting particulars for the claim, all us relevant to such event or circumstance at the same time as it notifies the Engineer of its claim. The Contractor shall keep such contemporary records as may be necessary to substantiate any claim, either on the Site or at another location acceptable to the Engineer. Without admitting the Employer's liability, the Engineer may, after receiving any notice under this sub-clause, monitor the record-keeping and/or instruct the Contractor to keep further contemporary records. The Contractor shall permit the Engineer to inspect all these records, and shall (if instructed) submit copies to the Engineer. Within 42 days after the Contractor became aware (or should have become aware) of the event or circumstance giving rise to the claim, or within such other period as may be proposed by the Contractor and approved by the Engineer, the Contractor shall send to the Engineer a fully detailed claim which includes full supporting particulars of the basis of the claim and of the extension of time and/or additional payment claimed. If the event or circumstance giving rise to the claim has a continuing effect:
Contractor's Claims. If the Contractor wishes to make a claim for a change in the Contract Price or the Contract Time, the Contractor shall give RMWD written notice thereof within ten (10) work days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work covered by the claim except in an emergency endangering life or property. No such claim shall be valid unless so made. Any change in the Contract Price or the Contract Time resulting from a claim that is approved by RMWD will be authorized by Change Order.
Contractor's Claims. When determining each extension of time under Sub-Clause 20.1, the Engineer shall review previous determinations and may increase, but shall not decrease, the total extension of time.
Contractor's Claims. If the Contractor considers himself to be entitled to any extension of the Time for Completion and/or any additional payment, under any Clause of these Conditions or otherwise in connection with the Contract, the Contractor shall give notice to the Engineer, describing the event or circumstance giving rise to the claim. The notice shall be given as soon as practicable, and not later than 28 days after the Contractor became aware, or should have become aware, of the event or circumstance. If the Contractor fails to give notice of a claim within such period of 28 days, the Time for Completion shall not be extended, the Contractor shall not be entitled to additional payment, and the Employer shall be discharged from all liability in connection with the claim. Otherwise, the following provisions of this Sub-Clause shall apply.
Contractor's Claims. 20.1 The number days referred to in the Clause is amended as follows: 1st Paragraph: 28 days amended to 14 days 2nd Paragraph: 28 days amended to 14 days 5th Paragraph: 42 days amended to 21 days Item Sub- Clause Data 6th Paragraph: 42 days amended to 21 days Obtaining Dispute Board Decision 20.4 The last sentence of the 1st Paragraph is amended as follows: Such reference shall be made within 14 days on the establishment of a dispute by either Party and shall state that it is given under this Sub-Clause. The number days referred to in the Clause is amended as follows: 4th Paragraph: 84 days amended to 28 days 5th Paragraph: 84 days amended to 28 days. 28 days amended to 14 days 7th Paragraph: 28 days amended to 14 days CONDITIONS OF CONTRACT GENERAL CONDITIONS The Conditions of Contract comprise the “General Conditions”, which form part of the “Conditions of Contract for Plant and Design-Build” First Edition 1999 published by Fédération Internationale des Ingénieurs-Conseils (FIDIC), and the following “Particular Conditions”, which include amendments and additions to such General Conditions. Copies of FIDIC Conditions of Contract, referred to above, may be obtained from: FIDIC Secretariat X.X. Xxx 00 XX 0000 Xxxxxxxx 00 Xxxxxxxxxxx Fax No: +00 00 000 0000
Contractor's Claims. 3.5 Metro’s Right to Stop, Perform, or Delete Work.
Contractor's Claims. If the Contractor considers himself to be entitled to any extension of the Time for Completion and/or any additional payment, the Contractor shall give notice to the Employer within 42 calendar days from the date the Contractor became aware or should have become aware of the event or circumstance giving rise to the claim. If the Contractor fails to do so, then the Contractor shall only be entitled to exten- sion of the Time for Completion and/or additional payment for delays and/or costs incurred after the date of the notice.
Contractor's Claims. The Architect shall render written decisions regarding claims, disputes or other matters in controversy between the District and the Contractor arising under the Construction Contract, including the execution or progress of work thereunder. The Architect’s decisions shall be in accordance with any applicable and reasonable time limits set forth in the Construction Contract; if no time limits are set forth, the Architect shall render decisions within a reasonable time.
Contractor's Claims. In the event of any Dispute between the Parties, either Party may call upon the Authority’s Engineer to mediate and assist the Parties in arriving at an amicable settlement thereof.
