Construction Review. The Independent Tester shall: Visit the Site and monitor the Works for their compliance with the Authority's Construction Requirements, Sub-hubco’s Proposals and the Approved RDD24. The frequency and timing of the Independent Tester's visits are dependent on the progress of construction on Site. The Contractor shall agree a programme with the Independent Tester for the inspection of key construction processes and the completed [Phases of the] Works and shall give the Independent Tester advance notice of these Works being carried out on Site. The Independent Tester shall identify any aspect of the Works which needs to be inspected before being covered over by subsequent activity so that he may satisfy himself that these have been constructed in accordance with the Contractor's Quality Plan without the need for opening up. Randomly check that the Works are being undertaken in accordance with the Construction Quality Plan that has been agreed by the Authority and Sub-hubco. Review the written Mechanical and Electrical engineering services testing and commissioning procedure. Undertake selective witnessing of the Mechanical and Electrical services testing and commissioning. The Independent Tester has indicated that these sampling proportions should amount to approximately [fifty] percent [(50%)]. The Independent Tester shall review [one hundred] percent [(100%)] of all test results. If in the professional judgment of the Independent Tester, because of the results of witnessing (or because of other circumstances) a different sampling percentage is appropriate he shall provide a detailed report in respect of that and any change in the percentage sampling resulting in a change of fees will be borne by Sub-hubco, the Authority or the Contractor as they shall agree, failing such agreement, as determined by the Dispute Resolution Procedure. Inspect rectification works which have previously prevented the Independent Tester from certifying the Project as complete. Concurrent with the issue of the Certificate of Practical Completion, agree a list of Snagging Matters with the Authority and Sub-hubco together with its programme for implementation and issue a Snagging Notice in accordance with Clause 18 of the Design Build Finance and Maintain Agreement. Check the production of the relevant operating manuals, relevant approvals, test results, inspection records and as built drawings and monitor the timely handover of this documentation.
Construction Review. A. The Engineer will periodically observe the construction of all work covered by this Contract. The Engineer, on behalf of the Owner, shall be authorized to determine the amount or quantities of the several items of work which are to be paid for under this Contract; to order field changes within the scope of the Contract and to render decisions on any questions which may arise relative to the execution of the work covered by this Contract. The Engineer does not have authority to suspend work on the project. The Trade Contractor shall not suspend any portion of the work nor resume suspended work without the written authority of the Owner.
Construction Review. The Consultant shall review and make recommendations upon the following:
Construction Review. The Manager shall maintain efficient supervision of the Work. The Manager shall evaluate the Work being performed at each Approved Project in light of the plans and specifications for such Approved Project. Following a request by the County, the Manager shall promptly upload to the Project Dataroom any documents or information requested by the County’s Authorized Representative relating to or concerning the development or construction of an Approved Project. The County’s monitoring and review, as set forth above, shall not in any way be construed as relieving the Manager of any of its obligations, responsibilities or liabilities under this Agreement.
Construction Review. For projects involving construction, CLIENT acknowledges that under generally accepted professional practice, interpretations of construction documents in the field are normally required, and that performance of construction-related services by the design professional for the project permits errors or omissions to be identified and corrected at comparatively low cost. CLIENT agrees to hold ENGINEER harmless from any claims resulting from performance of construction- related services by persons other than ENGINEER.
Construction Review. If construction administration and review services are requested by the OWNER, OWNER agrees to hold W&R harmless from any claims resulting from performance of construction- related services by persons other than W&R, and OWNER acknowledges that such administration, review, or interpretation of construction documents by W&R shall not relieve the related contractor from liability in regard to his duties and responsibilities for compliance with the engineering standards for the project.
Construction Review. The purpose of on-site reviews by the Owner’s Representative is to periodically observe the work in progress, the Service Provider’s interpretation of the construction documents, and to address questions with regard to the installation.
Construction Review. 1. Before Project construction begins, Mn/DOT and Wis/DOT shall meet with the construction contractor to ensure that construction plans are consistent with the approved Project design.
Construction Review. Construction Review by ENGINEER does not constitute a warranty or guarantee of any type. Construction contractors engaged by CLIENT shall be fully responsible for the quality of their own work and for adhering to the plans and specifications. ENGINEER shall not be responsible for the supervision and management of the work forces of the constructors, including the construction means, methods, techniques, sequences or safety procedures employed by the constructors to complete the work. CLIENT and CLIENT’S constructors shall promptly report to ENGINEER any alleged defects in the Work in order that ENGINEER may take prompt measures to remedy such alleged defects. ENGINEER may recommend to CLIENT the rejection of any Work that does not conform with ENGINEER’S recommendations, specifications or design.
Construction Review. If included in the scope of the service, ENGINEER shall observe the progress and content of the work to determine if the work is proceeding in general accordance with the Contract Documents. This construction review is intended to observe, document, and report information concerning the construction process. Observation of work at a project site shall not make ENGINEER responsible for the work performed by another party, the means, methods, techniques, sequences, or procedures selected by another party, nor the safety precautions or programs of another party.
