Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Operations Prior to Closing Between the date of the execution of this Agreement and Closing:
Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.
Operations Prior to the Closing Date (a) Seller shall use its commercially reasonable efforts to, and to cause the Companies to, operate and carry on the Business in the ordinary course and substantially as operated immediately prior to the date of this Agreement. Consistent with the foregoing, Seller shall use its commercially reasonable efforts, and shall cause the Companies to use their commercially reasonable efforts, consistent with good business practice, to preserve the goodwill of the suppliers, contractors, licensors, employees, customers, distributors and others having business relations with the Business.
Inspection Checklist (check one) ☐ In order to avoid disagreements about the condition of the Premises, at the time of accepting possession of the Premises, Tenant will complete the Inspection Checklist incorporated herein by reference and attached hereto as Exhibit B and record any damage or deficiencies that exist at the commencement of the Term. Landlord will be liable for the cost of any cleaning or repair to correct damages found at the time of the inspection. Tenant will be liable for the cost of any cleaning and/or repair to correct damages found at the end of the Term if not recorded on the inspection checklist, normal wear and tear excepted. ☐ The Tenant is NOT required to complete an inspection checklist.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
