Construction by the Lessee Sample Clauses

Construction by the Lessee. Use this paragraph if the Lessee is not permitted to do construction work: During the Term of this Lease, and any renewal, extension or holdover thereof, if the Lessee desires any additional work to be performed in the Demised Premises, it shall make a request for the same by submitting a Tenant Alteration Request form (hereinafter referred to as a “TAR”) to the Lessor, in accordance with the directions on the TAR. The TAR and instructions on how to complete it can be found on the OGS website at xxxxx://xxx.xx.xxx/tenant-alteration- request-tar-101-form. If the State determines that the requested work will be done, it will cause the same to be performed in a timely manner, at the Lessee’s sole cost and expense. The Lessee will be solely responsible to pay the State, as additional rent, the cost of all work performed under this section within thirty (30) days of receipt of an invoice of the same. In the event any construction, improvement, alteration, modification, addition, repair or replacement is made without the State’s consent, then the State shall remove or change such work to the reasonable satisfaction of the State, and the Lessee shall pay the cost thereof to the State, as additional rent, on demand. Use a-b below if the Lessee is permitted to do construction work:
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Construction by the Lessee. The Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without injury to the premises) without the prior consent of the Port Authority which consent will not be exercised arbitrarily, and in the event any construction, improvement, alteration, modification, addition, repair or replacement is made or done with or without such consent and unless the consent of the Port Authority shall expressly provide otherwise, the same shall immediately become the property of the Port Authority and the Lessee shall have no right to change or remove the same either during the term or at the expiration thereof. Notwithstanding the foregoing, immediately upon notice from the Port Authority given at any time during the letting, the Lessee shall remove or change any of the same made or done by it without the Port Authority's consent, and in the case of any of the same made or done with the Port Authority's consent, the Lessee if so required by notice from the Port Authority, shall remove or change the same immediately upon the expiration or termination of the letting, or immediately upon receipt of such notice as may be given within sixty (60) days after such expiration or termination provided, however, that if the Lessee so requests by written notice given to the Port Authority not earlier than one hundred twenty (120) days prior to, nor later than sixty (60) days after the expiration of the term of the letting, the Port Authority within thirty (30) days after receipt of such notice will notify the Lessee as to which construction, improvement, alteration, modification, repair or replacement made by the Lessee has to be removed or changed. With respect to any modifications, additions, alterations, improvements, installations or construction made or done by the Port Authority at the request of the Lessee either prior to or during the term of the letting, the Lessee shall have the same obligations as provided above with respect to that made or done by the Lessee with the Port Authority's consent.
Sample 1See All (4)
Construction by the Lessee. (a) Except as provided in paragraphs (i) and (j) of this Section, the Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without substantial injury to the premises) without the prior consent of the Port Authority, which shall not be arbitrarily and capriciously withheld, and the Port Authority shall not withhold such Consent except for reasons of safety, health, operational utility, impact on or compatibility of the proposed work on building systems, or other parts of the World Trade Center, or unless the proposed work, in the opinion of the Port Authority's Chief Engineer, acting in a non-arbitrary and non-capricious manner, shall fail to comply with (i) all governmental laws, ordinances, enactments, resolutions, rules and orders, including, without limitation, the enactments, ordinances, resolutions, and regulations of the City of New York and its various Departments, Boards and Bureaus that are applicable, or which would be applicable if the Port Authority were a private corporation, or (ii) all applicable requirements of the Port Authority's Tenant Construction Review Manual (hereinafter called the "Tenant Design Guide") issued by the Port Authority Engineering Department dated March, 1984, revised March, 1990, together with Amendment No. 1 dated October 1990 (as the same may be further amended in a non-arbitrary and non-capricious manner prior to the date the Lessee submits its plans and specifications) (the foregoing requirements in clauses (i) and (ii) hereinafter in this Agreement called the "Standards"). Except as provided below in this paragraph (a), any construction, improvement, alteration, modification, addition, repair or replacement made by or on behalf of Lessee, whether prior to or during the term, shall become the property of the Port Authority (subject to Lessee's right to use the same during the term of this Agreement and, to remove, modify, alter, improve, repair or replace the same in connection with construction and installation work performed in accordance with this Section 12 or otherwise in connection with the performance of Lessee's rights and obligations under this Agreement, provided, that any such removal, modification, alteration, improvement, repair or replacement shall be made in accordance with the applicable provisio...
Sample 1
Construction by the Lessee. The Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without injury to the premises) without the prior consent of the Port Authority, and in the event any construction, improvement, alteration, modification, addition, repair or replacement is made or done with or without such consent and unless the consent of the Port Authority shall expressly provide otherwise, the same shall immediately become
Sample 1
Construction by the Lessee. (a) The Lessee shall, prior to its submission to the Port Authority of the plans and specifications hereinafter provided for, submit to the Port Authority for its consent, the Lessee's comprehensive plan for the development of the site, including but not limited to renderings, layouts, locations, models, estimated commencement and completion dates, and preliminary functional plans.
Sample 1
Construction by the Lessee. (a) The following terms, when used in this Agreement, shall, unless the context shall require otherwise, have the respective meanings given below:
Sample 1
Construction by the Lessee 
Sample 1
AutoNDA by SimpleDocs

Related to Construction by the Lessee

  • Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

  • Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.

  • Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.

  • CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.

  • Removal of Improvements Except as otherwise expressly agreed to by Lessor and Lessee, Lessee shall have the right to remove all Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property installed by Lessee from the Premises upon the termination or expiration of this Lease, but in no event later than the date that is 120 days following the expiration or termination of this Lease (the “Removal Date”) and Lessor shall provide Lessee with access to the Premises at reasonable times until expiration of the Removal Date for the purpose of removing such items. Lessee shall provide Lessor with written notice of its election to remove the Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property from the Premises at least 60 days prior to the expiration of the Lease. If Lessee elects to remove the Tank Farm Assets and Improvements from the Premises after such removal Lessee shall restore any damage to the Premises and clean the Premises so as to eliminate therefrom any accumulation (other than any de minimis and non-hazardous accumulation) of foreign substances, materials, or debris, in addition to any Environmental Cleanup that may be required under Article 10. Lessee shall pay Lessor pro rata Rent (based on the amount of Rent applicable during the last month prior to the termination or expiration) through the date of Lessee’s complete removal of all such items. During the period of such removal and clean-up, all terms and conditions of this Lease, including, the indemnity and insurance provisions shall continue in full force and effect. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date, and provided that such facilities are in good working condition at the expiration of the Term (ordinary wear and tear excepted) then, such Tank Farm Assets and Improvements shall be deemed permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date and such facilities are not in good working condition at the expiration of the term (ordinary wear and tear excepted), or Lessee fails to so remove any or all of the Tank Farm Assets and Improvements from the Premises before the Removal Date, then, in addition to all rights and remedies available at law or in equity, without any prior notice, Lessor may (but shall be under no obligation), at Lessor’s option, deem such Tank Farm Assets and Improvements to be permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee, and Lessee shall reimburse Lessor for all costs of such removal and disposal upon demand from Lessor. If requested by Lessor, Lessee shall execute any and all documents necessary to evidence that title to the Tank Farm Assets and Improvements that Lessee does not remove by the Removal Date is in Lessor and to extinguish and remove any cloud or potential cloud on the title to the Premises and/or such facilities created by Lessee.

  • Surrender of Premises Ownership and Removal of Trade Fixtures 23.1 No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such subtenants or subtenancies.

  • IMPROVEMENTS AND ALTERATIONS 33. The Lessor agrees to furnish the demised premises to the Lessee at the fixturing date with those improvements set forth as Lessor's Improvements in Schedule "C" attached hereto. The Lessee agrees to be responsible for the installation at the fixturing date at its sole risk, cost and expense of the Lessee's Improvements in accordance with the rules and regulations as set forth in Schedule "D" attached hereto. Should the Lessee require any alterations, improvements, partitions, or changes of whatsoever kind to or in the demised premises after the Lessee has taken possession thereof, the Lessee will make and install the same at its own expense; PROVIDED HOWEVER, that no repairs, alterations, improvements, partitions, or changes of whatsoever kind shall be made without the written consent of the Lessor first had and obtained, such consent not to be unreasonably withheld; PROVIDED FURTHER, that any such repairs, alterations, improvements, partitions, or changes of whatsoever kind shall be made in a good and workmanlike manner with new, first-class materials and shall be carried out and the plans relating thereto shall be prepared by such tradesman, engineers or consultants as are approved by the Lessor. All alterations, improvements, partitions and changes made in or to the demised premises at any time before or after the taking of possession by the Lessee, by the Lessee or the Lessor, shall immediately become the property of the Lessor and form part of the demised premises and the building and shall remain upon the demised premises; PROVIDED ALWAYS that the Lessor may at the expiration or sooner termination of this Lease for any reason whatsoever require that the Lessee restore the demised premises in whole or in part to the same condition in which they were at the time of the entering into of this Lease, the exceptions to the Lessee's repair obligations only excepted. The Lessee shall not remove any furniture, leasehold improvements, fixtures, chattels of any kind from the demised premises without the prior consent of the Lessor and until all rents and other monies due are fully paid. SIGNS

  • Construction Representatives Landlord hereby appoints the following person(s) as Landlord's representative ("LANDLORD'S REPRESENTATIVE") to act for Landlord in all matters covered by this Work Letter Agreement: Tom Xxxxxxx. Xenant hereby appoints the following person(s) as Tenant's representative ("TENANT'S REPRESENTATIVE") to act for Tenant in all matters covered by this Work Letter Agreement: Georxx Xxxxxxxx. Xll communications with respect to the matters covered by this Work Letter Agreement are to made to Landlord's Representative or Tenant's Representative, as the case may be, in writing in compliance with the notice provisions of the Lease. Either party may change its representative under this Work Letter Agreement at any time by written notice to the other party in compliance with the notice provisions of the Lease.

  • Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.

Time is Money Join Law Insider Premium to draft better contracts faster.