Completion of IPO The IPO shall have been completed.
Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.
Extension of Initial Term Upon each annual anniversary date of this Agreement, this Agreement shall be extended automatically for successive terms of one year each, unless either the Corporation or the Employee gives contrary written notice to the other not later than the annual anniversary date.
Condition of Improvements The Improvements and the Tangible Personal Property (including but not limited to the mechanical systems, plumbing, electrical, wiring, appliances, fixtures, heating, air conditioning and ventilating equipment, elevators, boilers, equipment, roofs, structural members and furnaces) shall be in the same condition at Closing as they are as of the date hereof, reasonable wear and tear excepted. Prior to Closing, the Contributor shall not have diminished the quality or quantity of maintenance and upkeep services heretofore provided to the Real Property and the Tangible Personal Property and the Contributor shall not have diminished the Inventory. The Contributor shall not have removed or caused or permitted to be removed any part or portion of the Real Property or the Tangible Personal Property unless the same is replaced, prior to Closing, with similar items of at least equal quality and acceptable to the Acquiror.
Section 310 Computation of Interest Except as otherwise specified as contemplated by Section 301 for Securities of any series, interest on the Securities of each series shall be computed on the basis of a 360-day year of twelve 30-day months.
Termination of Indenture Upon payment in full of the Principal Amount of, Make-Whole Amount, if any, and all accrued and unpaid interest on and other amounts then due with respect to the Equipment Notes and provided that there shall then be no other amounts then due to the Note Holders and the Indenture Trustee hereunder or under the Lease or the Refunding Agreement or otherwise secured hereby, the Lien of this Indenture shall be deemed discharged and the security interests in favor of the Indenture Trustee and the Note Holders hereunder shall terminate, and the Owner Trustee shall direct the Indenture Trustee to execute and deliver to or as directed in writing by the Owner Trustee, an appropriate instrument evidencing the discharge of such Lien and the termination of such security interest in the Aircraft and release of the Indenture Documents from the assignment and pledge thereof hereunder, and the Indenture Trustee shall execute and deliver such instrument as aforesaid and, at the Owner Trustee's expense, will execute and deliver such other instruments or documents as may be reasonably requested by the Owner Trustee to give effect to such discharge, termination and release; provided, however, that this Indenture and the trusts created hereby shall earlier terminate and this Indenture shall be of no further force or effect as expressly provided pursuant to Article X hereof or upon any sale or other final disposition by the Indenture Trustee of all property part of the Trust Indenture Estate and the final distribution by the Indenture Trustee of all moneys or other property or proceeds constituting part of the Trust Indenture Estate in accordance with the terms hereof. Except as aforesaid otherwise provided, this Indenture and the trusts created hereby shall continue in full force and effect in accordance with the terms hereof.
Termination of Investment The obligation of the Investor to make an Advance to the Company pursuant to this Agreement shall terminate permanently (including with respect to an Advance Date that has not yet occurred) in the event that (i) there shall occur any stop order or suspension of the effectiveness of the Registration Statement for an aggregate of fifty (50) Trading Days, other than due to the acts of the Investor, during the Commitment Period, and (ii) the Company shall at any time fail materially to comply with the requirements of Article VI and such failure is not cured within thirty (30) days after receipt of written notice from the Investor, provided, however, that this termination provision shall not apply to any period commencing upon the filing of a post-effective amendment to such Registration Statement and ending upon the date on which such post effective amendment is declared effective by the SEC.
Termination of Interim Trust Agreement This Agreement (other than Article VI) and the trust created hereby shall terminate and be of no further force or effect upon the earlier of (i) the termination of the Trust pursuant to Section 9.1 of the Trust Agreement and (ii) the expiration of 21 years from the death of the last survivor of the descendants of Xxxxxx X. Xxxxxxx, the late Ambassador of the United States to the Court of St. James’s, living on the date hereof.
Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.
Period of Agreement This Agreement shall remain in full force and effect for a five year contract term commencing October 17, 2013, at 12:01 a.m., and ending 12:00 midnight, October 16, 2018. At reasonable times after August 1, 2018, the parties will meet to attempt to negotiate a new contract to be effective for the period beginning after midnight, October 16, 2018.
