Completion Audit Settlement and Closeout
Completion Audit Settlement and Closeout Sample Clauses
Related to Completion Audit Settlement and Closeout
Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out.
Contract Closeout Prior to the contract’s expiration date, Supplier may be provided contract close out documentation and shall complete, sign and return to VITA Supply Chain Management within 30 days of receipt. This documentation may include, but not be limited to: Patent/Royalty Certificate, Tangible Property/Asset Certificate, Escrow Certificate, SWaM Subcontracting Certification of Compliance, Sales Reports/IFA Payments Completion Certificate, and Final Payment Certificate. Supplier is required to process these as requested to ensure completion of close-out administration and to maintain a positive performance reputation with the Commonwealth of Virginia. Any closeout documentation not received within 30 days of Supplier’s receipt of the Commonwealth's request will be documented in the contract file as Supplier non-compliance. Supplier’s non-compliance may affect any pending payments due the Supplier, including final payment, until the documentation is returned.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for the entirety of the initial (1 year) contract period. A price escalation/de-escalation will be considered at the time of contract renewal and at 1-year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the contract renewal date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change % of Change x 100 = Percentage Change CPI-U Calculation Example: CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. If approved, the price adjustment shall become effective on the contract renewal date. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
PRELIMINARY APPROVAL OF SETTLEMENT 3. Promptly upon execution of this Stipulation, Lead Plaintiffs will move for preliminary approval of the Settlement, certification of the Settlement Class for settlement purposes only, and the scheduling of a hearing for consideration of final approval of the Settlement, which motion shall be unopposed by Defendants. Concurrently with the motion for preliminary approval, Lead Plaintiffs shall apply to the Court for, and Defendants shall agree to, entry of the Preliminary Approval Order, substantially in the form attached hereto as Exhibit A. RELEASE OF CLAIMS
Liquidation Settlement Procedures If at any time on or prior to the Termination Date for such Class the Aggregate Percentage Factor is greater than the Maximum Percentage Factor, then the Transferor shall immediately pay to the Administrative Agent, for the benefit of the Class Investors from previously received Collections, an amount equal to the amount such that, when applied in reduction of the Aggregate Net Investment, will result in an Aggregate Percentage Factor less than or equal to the Maximum Percentage Factor. Such amounts shall be applied pro rata to the reduction of the Net Investment for each Class of the Tranche Periods selected by the Class Agent for such Class. With respect to each Class, on the Termination Date for such Class and on each day thereafter, and on each day on which a Termination Event or Potential Termination Event has occurred and is continuing for such Class, the Collection Agent shall set aside and hold in trust for the applicable Class Investors for such Class (or deposit into the Collection Account if so required pursuant to Section 2.12 hereof) the Percentage Factor for such Class of all Collections received on such day and shall set aside and hold in trust for the Transferor such portion of Collections not allocated to the Class Investors. On each such Termination Date or the day on which a Termination Event or Potential Termination Event for such Class for which there is no grace period occurs, the Collection Agent shall deposit to the Administrative Agent’s account, for the benefit of the applicable Class Investors for such Class, any amounts set aside pursuant to Section 2.5 above. With respect to each Class, on the last day of each Tranche Period to occur on or after such Termination Date for such Class or during the continuance of a Termination Event or Potential Termination Event for such Class, the Collection Agent shall deposit to the Administrative Agent’s account to the extent not already so deposited, for the benefit of the Class Investors for such Class, the amounts so set aside for such Class Investors, pursuant to the second preceding sentence, but not to exceed the sum of (i) the accrued Discount (which, in the case of Discount computed by reference to the CP Rate with respect to any Class Conduit that utilizes “pool” funding, shall be determined for such purpose using the CP Rate most recently determined by the related Class Agent, multiplied by the Fluctuation Factor) for such Tranche Period (ii) the portion of the Net Investment allocated to such Tranche Period and (iii) all other Aggregate Unpaids owing to such Class Investors. On such day, the Collection Agent shall deposit to its account, from the amounts set aside for such Class, pursuant to the preceding sentence which remain after payment in full of the aforementioned amounts, the accrued Servicing Fee for such Tranche Period. If there shall be insufficient funds on deposit for the Collection Agent to distribute funds in payment in full of the aforementioned amounts, the Collection Agent shall distribute funds first, if the Transferor, Tech Data or any Affiliate of the Transferor or Tech Data is not then the Collection Agent, to the Collection Agent’s account, in payment of the Servicing Fee payable to the Collection Agent, second, in payment of all fees payable by the Transferor to the Administrative Agent or any of the Class Investors, third, in payment of the accrued Discount to each Class, fourth, in reduction of the Net Investment allocated to any Tranche Period ending on such date, fifth, in payment of all other Aggregate Unpaids owing to the Class Investors, as applicable, and sixth, if the Transferor, Tech Data or any Affiliate of the Transferor or Tech Data is the Collection Agent, to its account as Collection Agent, in payment of the Servicing Fee payable to such Person as Collection Agent. The Administrative Agent, upon its receipt of such amounts in the Administrative Agent’s account, shall distribute such amounts to the Class Investors, each as entitled thereto as set forth above; provided that if the Administrative Agent shall have insufficient funds to pay all of the above amounts in full on any such date, the Administrative Agent shall pay such amounts in the order of priority set forth above and, with respect to any such category above for which the Administrative Agent shall have insufficient funds to pay all amounts owing on such date, ratably (based on the amounts in such categories owing to such Persons) among all such Persons entitled to payment thereof. Following the date after all Termination Dates on which the Aggregate Net Investment has been reduced to zero, all accrued Discount and Servicing Fees have been paid in full and all other Aggregate Unpaids have been paid in full, (i) the Collection Agent shall recompute the Percentage Factor for each Class, (ii) the Administrative Agent, on behalf of the Class Investors, shall be considered to have reconveyed to the Transferor all of the Class Investors’ right, title and interest in and to the Affected Assets (including the Transferred Interest), (iii) the Collection Agent shall pay to the Transferor any remaining Collections set aside and held by the Collection Agent pursuant to the third sentence of this Section 2.6 and (iv) the Administrative Agent, on behalf of the applicable Class Investor(s), shall execute and deliver to the Transferor, at the Transferor’s expense, such documents or instruments as are necessary to terminate the Class Investors’ respective interests in the Affected Assets. Any such documents shall be prepared by or on behalf of the Transferor. On the last day of each Tranche Period, the Collection Agent shall remit to the Transferor such portion of Collections set aside for the Transferor pursuant to this Section 2.6.
Monetary Settlement Terms 3.1 Civil Penalty Payment
Preliminary Settlement Statement Seller and Buyer shall execute and deliver the Preliminary Settlement Statement.
DISPUTE SETTLEMENT PROCEDURE A major objective of this Agreement is to eliminate lost time and/or production arising out of disputes or grievances. Disputes over any work related or industrial matter should be dealt with as close to its source as possible. Disputes over matters arising from this agreement shall be dealt with according to the following procedure. An employee or the union delegate or site xxxxxxx or Enterprise should initially submit any work related grievance and/or industrial matter to the site foreperson, supervisor or other appropriate site representative of the company or appropriate site union representative as relevant. If the matter remains unresolved the union delegate or site xxxxxxx may then submit the matter to the appropriate senior management person. Where relevant the Enterprise may submit the matter to a union official. If still not resolved the delegate or site xxxxxxx shall refer the matter to an appropriate official of the union, who shall discuss the matter with the nominated representative of the Enterprise. If still not resolved there may be discussions between the state secretary and senior management representative. Whilst the above procedures are being followed work should continue as normal. This procedure is to be followed in good faith and without unreasonable delay by any party. Should the matter remain unresolved and where the issue is within the jurisdiction of the Victorian Building Industry Disputes Board (“the Board”), either of the parties shall refer the dispute at first instance to the Board (which shall deal with the dispute in accordance with VBIA procedures and, where required, determine issues of jurisdiction). The Board’s decision will be accepted by all parties subject to the right of either party to refer the dispute to the Australian Industrial Relations Commission for conciliation and if required arbitration. The Commission’s decision will be accepted by all parties subject to legal rights of appeal. This dispute settlement procedure does not apply to health and safety issues or issues of industry, state or national significance.
