Company Initiated Changes Sample Clauses

Company Initiated Changes. When a shift within an employee’s normal workweek is changed by the Company from one day to another, the employee shall be notified of the change forty-eight (48) hours in advance of the starting time on the earliest day involved in the change. If such notice is not given, the employee shall be paid time and one-half (1-1/2) for the hours worked on the newly scheduled day.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Company Initiated Changes. If at any time during the Term, the Company reasonably determines that it is necessary in the conduct of the Project to perform Additional Services not specifically provided for in the applicable Statement of Work, the Company shall prepare a Change Order describing in reasonable detail the nature of such Additional Services, and submit such Change Order to X4 for X4’s review and written approval. All Change Orders approved by X4 shall be signed by the Project Manager of each Party or by such other authorized representatives of the Company and X4 that the Project Managers may designate in writing. If any changes contemplated by a Change Order will, or are reasonably expected to, impact the estimated timing, Service Fees or scope of the Project and/or any Statement of Work, the Company shall provide X4 with a written description of such expected impact (including, if applicable, a written estimate of all such increased Service Fees) in the Change Order.
Sample 1

Related to Company Initiated Changes

  • Business Changes Change in any material respect the nature of the business of the Borrower or its Subsidiaries as conducted on the Effective Date.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

  • Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.

  • Implementation of Changes If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

  • Material Changes Except as contemplated in the Prospectus, or disclosed in the Company’s reports filed with the Commission, there shall not have been any material adverse change in the authorized capital stock of the Company or any Material Adverse Effect or any development that would reasonably be expected to cause a Material Adverse Effect, or a downgrading in or withdrawal of the rating assigned to any of the Company’s securities (other than asset backed securities) by any rating organization or a public announcement by any rating organization that it has under surveillance or review its rating of any of the Company’s securities (other than asset backed securities), the effect of which, in the case of any such action by a rating organization described above, in the reasonable judgment of the Agent (without relieving the Company of any obligation or liability it may otherwise have), is so material as to make it impracticable or inadvisable to proceed with the offering of the Placement Shares on the terms and in the manner contemplated in the Prospectus.

  • TECHNOLOGICAL CHANGES 18.07.01 The intent and purpose of the following Articles is to ensure that ample consideration is given to the effect technological change will have upon the job security and conditions of employment of employees as well as the continuing effectiveness of the Company.

  • MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.

Time is Money Join Law Insider Premium to draft better contracts faster.