Commencement of Performance. This Agreement is of no force and effect until signed by both parties and all JBE-required approvals are secured. Any commencement of performance prior to Agreement approval shall be at Contractor's own risk.
Commencement of Performance. This Agreement is of no force and effect until signed by both parties and all JBE-required approvals are secured. Any commencement of performance prior to Agreement approval shall be at Contractor's own risk. Stop Work Orders. The JBE may, at any time, by Notice to Contractor, require Contractor to stop all or any part of the Services for a period up to ninety (90) days after the Notice is delivered to Contractor, and for any further period to which the parties may agree (“Stop Work Order”). The Stop Work Order shall be specifically identified as such and shall indicate it is issued under this provision. Upon receipt of the Stop Work Order, Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the Services covered by the Stop Work Order during the period of stoppage. Within ninety (90) days after a Stop Work Order is delivered to Contractor, or within any extension of that period to which the parties shall have agreed, the JBE shall either (i) cancel the Stop Work Order; or (ii) terminate the Services covered by the Stop Work Order as provided for in this Agreement. If a Stop Work Order issued under this provision is canceled or the period of the Stop Work Order or any extension thereof expires, Contractor shall resume the performance of Services. The JBE shall make an equitable adjustment in the delivery schedule, the Contract Amount, or both, and the Agreement shall be modified, in writing, accordingly, if:
Commencement of Performance. This Agreement is of no force and effect until signed by the Court. Any commencement of performance prior to the Court’s signature shall be at Contractor's own risk.
Commencement of Performance. The Supplier shall commence performance upon receipt of written instructions from the Board.
Commencement of Performance. 29.1. If performance has not commenced within 60 days of the execution date of this Agreement, Xxxxxxx agrees to report by letter to Grantor the steps taken to initiate the program, the reasons for the delay, and the expected starting date.
Commencement of Performance. This Agreement is of no force and effect until signed by both parties and all Establishing JBE-required approvals are secured. Any commencement of performance prior to Agreement approval (and approval by a JBE of a Participating Addendum) shall be at Contractor's own risk. Stop Work Orders. Each JBE may, at any time, by Notice to Contractor, require Contractor to stop all or any part of the Work being provided to such JBE for a period up to ninety (90) days after the Notice is delivered to Contractor, and for any further period to which the JBE and the Contractor may agree (“Stop Work Order”). The Stop Work Order shall be specifically identified as such and shall indicate it is issued under this provision. Upon receipt of the Stop Work Order, Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the Work covered by the Stop Work Order during the period of stoppage. Within ninety (90) days after a Stop Work Order is delivered to Contractor, or within any extension of that period to which the parties shall have agreed, the JBE shall either (i) cancel the Stop Work Order; or (ii) terminate the Work covered by the Stop Work Order as provided for in this Agreement. If a Stop Work Order issued under this provision is canceled or the period of the Stop Work Order or any extension thereof expires, Contractor shall resume the performance of the Work. The JBE shall make an equitable adjustment in the delivery schedule and the Participating Addendum shall be modified, in writing, accordingly, if:
Commencement of Performance. The Contractor shall commence performance upon receipt of written instructions from the County.
Commencement of Performance. CONSULTANT shall not perform any work under this Agreement until: (i) CONSULTANT furnishes proof of insurance as required under Sections 7 and 22 of this Agreement, and (ii) CITY provides CONSULTANT a signed Professional Services Agreement, which shall serve as a Notice to Proceed. All services required of CONSULTANT under this Agreement shall be completed on or before the end of the term of the Agreement.
Commencement of Performance. This Agreement is of no force and effect until signed by both parties and all Judicial Council-required approvals are secured. Any commencement of performance prior to Agreement approval shall be at Consultant's own risk.
Commencement of Performance. (a) FIRM will not commence or perform any work under this Agreement until:
