Collection Schedules Sample Clauses

Collection Schedules. The CONTRACTOR agrees to maintain the following collection schedules throughout the terms of the Contract.
Sample 1
AutoNDA by SimpleDocs
Collection Schedules. Collection Contractor shall collect all Solid Waste and Recyclable Materials in conformance with the weekday(s) and number of pulls as specified in Exhibit E. Where no weekday is specified, Collection Contractor shall adhere to the following schedule: (a) when four (4) weekly collections are required, collections may be made on any four (4) Business Days; (b) when three (3) weekly collections are required, collections shall be made on Monday, Wednesday and Friday of each week; (c) when two (2) weekly collections are required, collections shall be made on any two non-consecutive Business Days each week, and Friday and Monday shall be considered consecutive Business Days; and (d) when one (1) weekly collection is required, such collection shall be on the same weekday each week. A modified schedule may occur during extended breaks, such as Spring, Winter and/or Summer Break(s), including “on call collection” which may be less frequent than once per week. Included are currently available school calendars for the School District. The calendar, as well as the current collection schedules included in each respective Exhibit E, are subject to change in the School District's sole discretion. No later than ten (10) days before commencing Collection Services for the School District, Collection Contractor shall furnish that School District, a weekly collection schedule that conforms to the specifications set forth in the School District's Exhibit E or, if and/or where applicable, the schedule set forth in this section.
Sample 1
Collection Schedules 
Sample 1

Related to Collection Schedules

  • Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.

  • Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:

  • Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include:  Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned  Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration.  The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback.  At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance.  Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter:

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Schedules Schedules to this Agreement form a part of it.

  • Amortization Schedule We do not provide an initial amortization schedule at the time of project agreement release but maintain a "Loan Summary Spreadsheet" on our website on the Financial Tab under "Loans". Once your loan is put into billing an amortization schedule will be posted to the same website, with a copy mailed to the Chief Financial Officer the month following project closeout.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Wage Schedules The Parties shall, upon completing a wage adjustment calculation, forthwith prepare, publish, post and distribute a wage schedule resulting therefrom. The final determination of the wage schedules shall be issued no later than the 7th day of March or September, for the May and November adjustments, respectively.

  • Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................

  • Outage Schedules The Connecting Transmission Owner shall post scheduled outages of its transmission facilities on the NYISO OASIS. Developer shall submit its planned maintenance schedules for the Large Generating Facility to Connecting Transmission Owner and NYISO for a minimum of a rolling thirty-six month period. Developer shall update its planned maintenance schedules as necessary. NYISO may direct, or the Connecting Transmission Owner may request, Developer to reschedule its maintenance as necessary to maintain the reliability of the New York State Transmission System. Compensation to Developer for any additional direct costs that the Developer incurs as a result of rescheduling maintenance, including any additional overtime, breaking of maintenance contracts or other costs above and beyond the cost the Developer would have incurred absent the request to reschedule maintenance, shall be in accordance with the NYISO OATT. Developer will not be eligible to receive compensation, if during the twelve (12) months prior to the date of the scheduled maintenance, the Developer had modified its schedule of maintenance activities other than at the direction of the NYISO or request of the Connecting Transmission Owner.

Time is Money Join Law Insider Premium to draft better contracts faster.