Changes After Plans Are Approved Sample Clauses

Changes After Plans Are Approved. If Tenant shall desire, or any governmental body shall require, any changes, alterations, or additions to the Approved Plans, Tenant shall submit a detailed written request or revised Plans (the “Change Order”) to Landlord for approval, which written request or revised Plans shall be reviewed by Landlord in the manner provided for in Section II.b. above. If reasonable and practicable and generally consistent with the Plans theretofore approved, Landlord shall not unreasonably withhold, condition or delay its approval. All costs in connection therewith, including, without limitation, construction costs, permit fees, and any additional plans, drawings and engineering reports or other studies or tests, or revisions of such existing items, shall be included in the Costs of the Work under Section VI. In the event that the Premises are not constructed in substantial accordance with the Approved Plans, Tenant shall not be permitted to occupy the Premises until the Premises reasonably comply in all respects therewith; in such case, the Rent shall nevertheless commence to accrue and be payable as otherwise provided in the Lease Document.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Changes After Plans Are Approved. If Tenant shall desire any changes, alternations, or additions to the final Plans after they have been approved by Landlord, Tenant shall submit a detailed written request or revised Plans (the “Change Order”) to the Landlord for approval. If reasonable and practicable and generally consistent with the Plans theretofore approved, Landlord shall not unreasonably withhold approval; but all costs in connection therewith, including construction costs, permit fees, and any additional plans, drawings, engineering reports, or other studies or tests, or revisions of such existing items, shall be paid for by Tenant as a Tenant’s Cost under ¶ 9.1.
Sample 1Sample 2Sample 3See All (8)
Changes After Plans Are Approved. If Tenant shall desire any changes, alterations, or additions to the Plans after they have been approved by Landlord, Tenant shall submit a detailed written request or revised Plans (the "Change Order") to Landlord for approval. If reasonable and practicable and generally consistent with the Plans theretofore approved, Landlord shall not unreasonably withhold approval, but all costs in connection therewith, including, without limitation, construction costs, permit fees, and any additional plans, drawings and engineering reports or other studies or tests, or revisions of such existing items, shall be paid for by Tenant as a Tenant's Cost under Section IV. The cost of any corrections for errors or omissions made by any space planner, architect, engineer or contractor recommended or engaged by Tenant, including corrections for unforeseen or concealed conditions, shall be borne by Tenant.
Sample 1Sample 2Sample 3See All (7)
Changes After Plans Are Approved. If Tenant shall desire, or any governmental body shall require, any material changes, alterations, or additions to the Approved Plans other than for minor changes of the type that may be approved through the authority of an architect under AIA Document A201-2007 General Conditions of the Contract for Construction or adjustments to deal with field conditions which the Tenant’s contractor is authorized to make without prior approval, Tenant shall submit a detailed written request or revised Plans (the “Change Order”) to Landlord for approval which approval shall not be unreasonably withheld. Landlord shall approve or disapprove such Change Order within three (3) working days after receipt. All costs in connection therewith, including, without limitation, construction costs, permit fees, and any additional plans, drawings and engineering reports or other studies or tests, or revisions of such existing items, shall be included in the Cost of the Tenant’s Work under Section IV. No delays resulting from any Change Orders or requests therefor shall delay the Commencement Date or Commencement of Rent. In the event that the Premises are not constructed in accordance with the Approved Plans, Tenant shall not be permitted to occupy the Premises until the Premises reasonably comply in all material respects therewith; in such case, the Rent shall nevertheless commence to accrue and be payable as otherwise provided in the Lease.
Sample 1
Changes After Plans Are Approved. If Tenant shall desire, or any governmental body shall require, any changes, alterations, or additions to the Approved Plans, Tenant shall submit a detailed written request or revised Plans (the “Change Order”) to Landlord for approval. If reasonable and practicable and generally consistent with the Plans theretofore approved, Landlord shall not unreasonably withhold, condition or delay approval, and in any event Landlord shall not withhold approval to any changes to the Approved Plan required by any governmental body. The provisions of Section IIb shall govern and control such approval. All costs in connection therewith, including, without limitation, construction costs, permit fees, and any additional plans, drawings and engineering reports or other studies or tests, or revisions of such existing items, shall be included in the Cost of Tenant’s Work under Section IV. No delays resulting from any Change Orders or requests therefor shall delay any Commencement Date or commencement of Rent. Landlord shall cooperate fully with Tenant, Tenant’s Architect and construction consultants in providing any information deemed necessary by Tenant for the planning, pricing and completion of Tenant’s Work. Tenant shall pay Landlord all out-of-pocket costs and expenses incurred by Landlord in connection with Landlord’s review or approval of the Plans, but Tenant shall not be required to pay to Landlord any fee for any supervision, review or coordination with respect to Tenant’s Work.
Sample 1
Changes After Plans Are Approved. If Lessee desires any changes, alterations, or additions to the Plans after they have been approved, Lessee shall submit a detailed written request or revised Plans (the “Change Order”) to Lessor for approval. If reasonable, practicable and generally consistent with the Plans theretofore approved, Lessor shall not unreasonably withhold approval. In the event that a bid for the Tenant Improvements has already been accepted at the time such Change Order is approved, then upon Lessor’s approval thereof, Lessor shall require the contractor to identify the additional costs resulting from such Change Order, and Lessor shall notify Lessee of such cost in writing. In such event, such Change Order shall not be effective unless Lessee approves the cost of such Change Order in writing.
Sample 1
Changes After Plans Are Approved. If Tenant shall desire any changes, alterations, or additions to the final Plans after they have been approved by Landlord, Tenant shall submit a detailed written request or revised Plans (the "Change Order") to the Landlord for approval. If reasonable and practicable and generally consistent with the Plans theretofore approved, Landlord shall not unreasonably withhold approval; but all costs in connection therewith shall be paid for by Tenant as a Tenant's Cost under Paragraph 4 to the extent that such costs exceed the amount expected to be incurred by Landlord under the previous plans. Landlord's approval of any Change Order shall be contingent upon Tenant's acknowledgement and agreement to any delay in the date of substantial completion which may be caused by such Change Order. 4.
Sample 1
AutoNDA by SimpleDocs

Related to Changes After Plans Are Approved

  • GOODS RE-ENTERED AFTER REPAIR OR ALTERATION 1. No Party may apply a customs duty to a good, regardless of its origin, that re-enters its territory after that good has been temporarily exported from its territory to the territory of another Party for repair or alteration, regardless of whether such repair or alteration could be performed in the territory of the Party from which the good was exported for repair or alteration.

  • Completion of Concrete Pours and Emergency Work 24.14.1 Except as provided in this sub-clause an employee shall not work or be required to work in the rain.

  • Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract.‌ If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.

  • ADOPTION OF BUDGET The budget shall be approved and signed below by members of the School Board. Adopted this day of , 20 by a roll call vote of Yeas, and Xxxx, to wit: ** MEMBERS VOTING YEA: ** MEMBERS VOTING NAY: * Based on the 23 Illinois Administrative Code-Part 100 and inconformity with Section 17-1 of the School Code. ** Type in the members who voted "YEA" nor "NAY". Actual school board member signatures are not required for electronic submission.

  • Certain Additional Matters (a) Any arbitration award shall be a bare award limited to a holding for or against a party and shall be without findings as to facts, issues or conclusions of law (including with respect to any matters relating to the validity or infringement of patents or patent applications) and shall be without a statement of the reasoning on which the award rests, but must be in adequate form so that a judgment of a court may be entered thereupon. Judgment upon any arbitration award hereunder may be entered in any court having jurisdiction thereof.

  • CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.

  • Events Relating to Plans and Benefit Arrangements Any of the following occurs: (i) any Reportable Event, which the Agent determines in good faith constitutes grounds for the termination of any Plan by the PBGC or the appointment of a trustee to administer or liquidate any Plan, shall have occurred and be continuing; (ii) proceedings shall have been instituted or other action taken to terminate any Plan, or a termination notice shall have been filed with respect to any Plan; (iii) a trustee shall be appointed to administer or liquidate any Plan; (iv) the PBGC shall give notice of its intent to institute proceedings to terminate any Plan or Plans or to appoint a trustee to administer or liquidate any Plan; and, in the case of the occurrence of (i), (ii), (iii) or (iv) above, the Agent determines in good faith that the amount of the Borrower's liability is likely to exceed 10% of its Consolidated Tangible Net Worth; (v) the Borrower or any member of the ERISA Group shall fail to make any contributions when due to a Plan or a Multiemployer Plan; (vi) the Borrower or any other member of the ERISA Group shall make any amendment to a Plan with respect to which security is required under Section 307 of ERISA; (vii) the Borrower or any other member of the ERISA Group shall withdraw completely or partially from a Multiemployer Plan; (viii) the Borrower or any other member of the ERISA Group shall withdraw (or shall be deemed under Section 4062(e) of ERISA to withdraw) from a Multiple Employer Plan; or (ix) any applicable Law is adopted, changed or interpreted by any Official Body with respect to or otherwise affecting one or more Plans, Multiemployer Plans or Benefit Arrangements and, with respect to any of the events specified in (v), (vi), (vii), (viii) or (ix), the Agent determines in good faith that any such occurrence would be reasonably likely to materially and adversely affect the total enterprise represented by the Borrower and the other members of the ERISA Group;

  • MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.

  • Alterations, Additions, and Improvements Lessee covenants and agrees with Lessor not to permit the Premises to be used for any purpose other than that stated in Section 5 hereof or make or allow to be made any alterations or physical additions in or to the Premises without first obtaining the written consent of Lessor in each such instance. Lessor's consent shall not be required for nonstructural alterations made by Lessee from time to time as necessary to adapt the Premises for the uses and business purposes permitted hereby, provided that such alterations do not affect any part of the Building other than the Premises, are not visible from outside the Building and do not adversely affect any service required to be furnished by Lessor to Lessee or to any other tenant or occupant of the Building. Lessee shall be responsible for any lien filed against the Premises or any portion of the Building for work claimed to have been done for, or materials claimed to have been furnished to Lessee. Any and all such alterations, physical additions, or improvements, when made to the Premises by Lessee, shall be at Lessee's expense and shall at once become the property of Lessor and shall be surrendered to Lessor upon termination of this Lease by lapse of time or otherwise; provided, however, this clause shall not apply to the movable fixtures, office equipment, and other personal property owned by Lessee. Tenant Initials ___________ Landlord Initials___________ 4Section 17. Legal Use and Violations of Insurance Coverage. ----------- ----------------------------------------------- Lessee covenants and agrees with Lessor not to occupy or use, or permit any portion of the Premises to be occupied or used, for any business or purpose which is unlawful, disreputable, or deemed to be extra-hazardous on account of fire, or permit anything to be done which would in any way increase the rate of fire, liability, or any other insurance coverage on the Building and/or its contents.

  • Implementation of Corrective Action Plan After the Corrective Action Plan is finalized, the Purchasers shall use reasonable best efforts to implement the finalized Corrective Action Plan on the timeline set forth therein and provide periodic reports (as provided for therein) to the Sellers on the status of their implementation of the Corrective Action Plan.

Time is Money Join Law Insider Premium to draft better contracts faster.