Change of Contract Times. 17.2.1 The Contract Times (or Milestones) may only be changed by a Change Order. Approved Changes in the Contract Times or accepted Claims that affect the Contract Times will be addressed through the Change Order process provided in this Agreement.
Change of Contract Times. A. The Contract Times (or Milestones) may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contract Times (or Milestones) shall be based on written notice submitted by the party making the claim to the ENGINEER and the other party to the Contract in accordance with the provisions of paragraph 10.05.
Change of Contract Times. The Contract Times may only be changed by a Change Order. All changes in the Contract Price and/or adjustments to the Contract Times related to each change shall be included in Contractor’s change order proposal. No cost or time will be allowed for cumulative effects of multiple changes. All Change Orders must state that the Contract Time is not changed or is either increased or decreased by a specific number of days. Failure to include a change to time shall waive any change to the time unless the parties mutually agree in writing to postpone a determination of the change to time resulting from the Change Order. Notice of the amount of the request for adjustment in the Contract Times with supporting data shall be delivered within seven (7) Days after such start of occurrence, unless MTS allows an additional period of time to ascertain more accurate data in support of the request. No extension of time or additional compensation shall be given for a delay if the Contractor failed to give notice in the manner and within the time prescribed. MTS may elect, at MTS’s sole discretion, to grant an extension in Contract Times, without Contractor’s request, because of delays or other factors. Float is for the benefit of the Project. Float shall not be considered for the exclusive use or benefit of either MTS or the Contractor. Contractor shall not be entitled to compensation, and MTS will not compensate Contractor, for delays which impact early completion. Any difference in time between the Contractor’s early completion and the Contract Time shall be considered a part of the Project float. Contractor’s entitlement to an extension of the Contract Times is limited to an MTS- caused extension of the critical path, reduced by the Contractor’s concurrent delays, and established by a proper time impact analysis. No time extension shall be allowed unless, and then only to the extent that, the MTS-caused delay extends the critical path beyond the previously approved Contract
Change of Contract Times. A. The Contract Times may only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Times shall comply with the provisions of Paragraph
Change of Contract Times. A. The Contract Time(s) (or Milestones) may only be changed by a Change Order. Any claim for an adjustment of the Contract Time(s) (or Milestones) shall be based on written notice pursuant to Paragraph 15.02. All adjustments for additional time must include a detailed critical path analysis of the Contract schedule.
Change of Contract Times. 11.0 The Contract Times (or Milestones) may only be changed by a Change Order or a Written Amendment. Any claim for an adjustment of the Contract Times (or Milestones) shall be based on written notice delivered by the party making the claim to the other party and to Project Manager promptly (but in no event later than fifteen days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within thirty days after such occurrence (unless Project Manager allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Times (or Milestones) shall be determined by Project Manager in accordance with paragraph 8.2.5 if the Town and Contractor cannot otherwise agree. No claim for an adjustment in the Contract Times (or Milestones) will be valid if not submitted in accordance with the requirements of this paragraph.
Change of Contract Times. A. The Contract Times may only be changed by a Change Order.
Change of Contract Times
