Caused Delays Sample Clauses

Caused Delays. The Expansion Commencement Date shall occur as provided in this Third Amendment, provided that the same shall be extended by the number of days of actual delay of the substantial completion of the Expansion Premises Improvements to the extent caused by a "Landlord Caused Delay," as that term is defined, below, but only to the extent such Landlord Caused Delay causes the substantial completion of the Expansion Premises Improvements to occur after the date which is five (5) months following the date upon which the Expansion Premises is delivered to Tenant. As used herein, "Landlord Caused Delay" shall mean actual delays in the substantial completion of the Expansion Premises Improvements to the extent resulting from interference (when judged in accordance with industry custom and practice) with Tenant's construction of the Expansion Premises Improvements to the extent caused by (i) Landlord's failure to timely approve or disapprove any matter requiring Landlord's pertaining to the Expansion Premises Improvements within the time periods set forth above or if not specified, within a reasonable period of time; (iii) Landlord's failure to timely disburse the Expansion Premises Improvement Allowance; (ii) material and unreasonable interference by Landlord with substantial completion of the Expansion Premises if such interference (A) objectively precludes or delays the construction of tenant improvements in the Building or any portion thereof, and (B) relates to access by Tenant to the Expansion Premises or any of the Building's facilities (including loading docks and freight elevators) or services and utilities (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; or (iii) the negligence or willful misconduct of Landlord or the Landlord Parties pertaining to the Premises. If Tenant contends that a Landlord Caused Delay has occurred, Tenant shall notify Landlord in writing of the event which constitutes such Landlord Caused Delay. Tenant will additionally use reasonable efforts to mitigate the effects of any Landlord Caused Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. In addition, Tenant shall endeavor to provide notice to Landlord when Tenant becomes aware of any expected or potential Landlord Ca...
Sample 1Sample 2
AutoNDA by SimpleDocs
Caused Delays. To the extent there shall be a delay or there are delays in the “Substantial Completion of the Tenant Improvements,” as that term is defined in Section 4.3, below, due to a “Landlord Caused Delay,” then the applicable Lease Commencement Date shall be extended for each “Landlord Delay Day,” as that term is defined in Section 4.6, below. As used in this Tenant Work Letter, “Landlord Caused Delay” shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to timely approve or disapprove any Construction Drawings within the time period set forth herein; (ii) material interference by Landlord, its agents, employees or contractors with the Substantial Completion of the Tenant Improvements and which objectively preclude or delay the construction of Tenant Improvements in the Building by any person, which interference relates to access by Tenant, or the Contractor to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein to the extent within Landlord’s reasonable control) during normal construction hours, or the use thereof during normal construction hours; (iii) delays due to the acts or failures to act of Landlord, its agents, employees or contractors including without limitation any such acts or failures to act with respect to payment of the Allowances as provided herein.
Sample 1

Related to Caused Delays

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Permitted Delays The Company shall be entitled to postpone the filing of any Registration Statement under Section 2.3 if (i) at any time prior to the filing of such Registration Statement the Board of Directors of the Company determines, in its good faith business judgment, that such registration and offering would materially and adversely affect any financing, acquisition, corporate reorganization or other material transaction involving the Company, and (ii) the Company delivers the Holders requesting such registration written notice thereof within 10 business days of the date of receipt of such request; provided, that all such periods of postponement may not exceed 45 days during any 365-day period.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

Time is Money Join Law Insider Premium to draft better contracts faster.