Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted
