Development Activities The Development activities referred to in item “b” of paragraph 3.1 include: studies and projects of implementation of the Production facilities; drilling and completion of the Producing and injection xxxxx; and installation of equipment and vessels for extraction, collection, Treatment, storage, and transfer of Oil and Gas. The installation referred to in item “c” includes, but is not limited to, offshore platforms, pipelines, Oil and Gas Treatment plants, equipment and facilities for measurement of the inspected Production, wellhead equipment, production pipes, flow lines, tanks, and other facilities exclusively intended for extraction, as well as oil and gas pipelines for Production Outflow and their respective compressor and pumping stations.
PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board agrees to implement the following:
Professional Development Activities Professional development activities are activities initiated by individual faculty members or groups of faculty members and may include attendance at conferences, workshops or seminars which facilitate the following:
Diagnostic Assessment 6.3.1 Boards shall provide a list of pre-approved assessment tools consistent with their Board improvement plan for student achievement and which is compliant with Ministry of Education PPM (PPM 155: Diagnostic Assessment in Support of Student Learning, date of issue January 7, 2013).
Cyber incident damage assessment activities If DoD elects to conduct a damage assessment, the Contracting Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
Environmental Assessment and Mitigation Development of a transportation project must comply with applicable environmental laws. The party named in article 1, Responsible Parties, under AGREEMENT is responsible for the following:
PROJECT ACTIVITIES Grantee must perform the project activities set forth on Exhibit A (the “Project”), attached hereto and incorporated in this Grant by this reference, for the period beginning on the Effective Date and ending June 30, 2021 (the “Performance Period”).
Development cooperation 1. The Parties recognise that development cooperation is a crucial element of their Partnership and an essential factor in the realisation of the objectives of this Agreement as laid down in Article 1. This cooperation can take financial and non-financial forms.
Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.
