Authority of Architect Sample Clauses

Authority of Architect. Project Inspector, and DSA: Contractor hereby acknowledges that the Architect(s), the Project Inspector(s), and the Division of the State Architect have authority to approve and/or suspend Work if the Contractor’s Work does not comply with the requirements of the Contract Documents, Title 24 of the California Code of Regulations, and all applicable laws and regulations. The Contractor shall be liable for any delay caused by its non-compliant Work.
Sample 1Sample 2Sample 3See All (24)
AutoNDA by SimpleDocs
Authority of Architect. Notwithstanding any contrary provision hereof or of any Contract Document, no consent, decision, determination, approval or certification to be made by Architect hereunder shall be binding upon Owner unless and to the extent agreed to in writing by Owner.
Sample 1Sample 2Sample 3
Authority of Architect. Contractor hereby acknowledges that the Architect has authority to approve and/or stop Work if the Contractor’s Work does not comply with the requirements of the Contract Documents and all applicable laws. The Contractor shall be liable for any delay caused by its non-compliant Work.
Sample 1
Authority of Architect. The Architect shall advise and consult with the Owner (1) during the Contract Administration Phase, and (2) by an amendment to this Agreement, from time to time during the correction period described in the Contract for Construction. The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement unless otherwise modified by written instrument.
Sample 1
Authority of Architect. Architect's authority is limited to its scope of authority set forth in this Agreement and the General Conditions. Notwithstanding anything else stated in this Agreement or any of the Contract Documents, Architect does not have the express or implied authority to obligate County to any expenditure of money or extension of contractual time periods, including, without limitation, any adjustment to the price or time of performance of any contract between County and the Contractor, a Separate Contractor, a County Consultant or any other third person or entity.
Sample 1

Related to Authority of Architect

  • Authority of Arbitrator The expedited arbitrator shall have the same powers and authority as an arbitration board established under the provisions under the Labour Relations Code.

  • Authority of Arbitration Board The Arbitration Board shall have the power to settle the terms of the question to be arbitrated.

  • Authority of Advisor (a) Pursuant to the terms of this Agreement (including the restrictions included in this Section 4 and in Section 9), and subject to the continuing and exclusive authority of the Board over the supervision of the Company, the Company, acting on the authority of the Board of Directors, hereby delegates to the Advisor the authority to perform the services described in Section 3.

  • Authority of the Manager The Manager for, and in the name and on behalf of the Company, is hereby authorized to:

  • Authority of the Representatives Any action by the Underwriters hereunder may be taken by the Representatives on behalf of the Underwriters, and any such action taken by the Representatives shall be binding upon the Underwriters.

  • Authority of the Representative Any action by the Underwriters hereunder may be taken by the Representative on behalf of the Underwriters, and any such action taken by the Representative shall be binding upon the Underwriters.

Time is Money Join Law Insider Premium to draft better contracts faster.