Assistance in Litigation or Administrative Proceedings Covered Entity shall provide written notice to Business Associate if litigation or administrative proceeding is commenced against Covered Entity, its directors, officers, or employees, based on a claimed violation by Business Associate of HIPAA, the HIPAA Rules or other laws relating to security and privacy or PHI. Upon receipt of such notice and to the extent requested by Covered Entity, Business Associate shall, and shall cause its employees, Subcontractors, or agents assisting Business Associate in the performance of its obligations under the Contract to, assist Covered Entity in the defense of such litigation or proceedings. Business Associate shall, and shall cause its employees, Subcontractor’s and agents to, provide assistance, to Covered Entity, which may include testifying as a witness at such proceedings. Business Associate or any of its employees, Subcontractors or agents shall not be required to provide such assistance if Business Associate is a named adverse party.
GRIEVANCE AND ARBITRATION PROCEDURES 8.01 For the purposes of this Agreement, a grievance is defined as a difference arising between the parties related to the interpretation, application, administration or alleged violation of the Agreement including any question as to whether a matter is arbitrable.
Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.
GRIEVANCE PROCEDURE AND ARBITRATION 8.01 For purposes of this Agreement, a grievance is defined as a difference arising between the parties relating to the interpretation, application, administration or alleged violation of the Agreement including any question as to whether a matter is arbitrable.
Arbitration Process Any arbitration will be conducted pursuant to the applicable rules (the “Arbitration Rules”) of the American Arbitration Association, as modified herein, to the extent such modifications are not prohibited by the Arbitration Rules. The arbitration will be conducted in Indianapolis, Indiana. The parties will select a single arbitrator, but in the event that the parties are unable to agree, the arbitrator will be appointed pursuant to the Arbitration Rules. The arbitrator will be a practicing attorney with significant expertise in litigating and/or presiding over cases involving the substantive legal areas involved in the dispute. The parties to the arbitration will not request, and the arbitrator will not order, that any discovery be taken or provided, including depositions, interrogatories or document requests, except to the extent the amount in controversy exceeds $50,000. The arbitration will be concluded within three months of the date the arbitrator is appointed. The arbitrator’s findings, reasoning, decision, and award will be stated in writing and based upon applicable law. Judgment on the arbitration award may be entered in any court having jurisdiction. In the event that the arbitration results in an award which imposes an injunction or contains a monetary award in excess of $100,000, the award will be reviewable on appeal initiated by filing notice of appeal with the AAA office within 30 days of the award, governed by the AAA Optional Appellate Arbitration Rules and conducted by a panel of three new arbitrators, ruling by majority, under the procedure for appointment from the national roster of arbitrators. Unless the applicable Arbitration Rules require otherwise, arbitration fees and costs will be shared equally by the claimant(s) and respondent(s), respectively, in any arbitration proceeding. Should the AAA be unavailable, unable or unwilling to accept and administer the arbitration of any claim under these arbitration provisions as written, the parties will agree on a substitute arbitration organization, such as JAMS, that will enforce the arbitration provisions as written. Because this Agreement memorializes a transaction in interstate commerce, the Federal Arbitration Act governs the interpretation and enforcement of these arbitration provisions. More information about arbitration, including the Arbitration Rules, is available at xxx.xxx.xxx or by calling 0-000-000-0000.
