Approval Delays To the Knowledge of Acquiror, there is no reason why the granting of any of the Requisite Regulatory Approvals would be denied or unduly delayed. Acquiror Bank’s most recent CRA rating was “satisfactory” or better.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Mutual Deliveries At the Closing, Purchaser and Seller shall mutually execute and deliver each to the other:
Conversion Delays If the Company fails to deliver shares in accordance with the timeframe stated in Section 1.00(b), the Holder, at any time prior to selling all of those shares, may rescind any portion, in whole or in part, of that particular conversion attributable to the unsold shares. The rescinded conversion amount will be returned to the Principal Sum with the rescinded conversion shares returned to the Company, under the expectation that any returned conversion amounts will tack back to the Effective Date.
Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Additional Deliveries Mezzanine Lender shall have received such other deliveries reasonably requested by Mezzanine Lender, provided such requests are customary and are consistent with the deliveries required with respect to the Properties on the Closing Date.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
