Acts of God or Force Majeure. KCSM will not be liable for losses, damages, missing parts or harm suffered by the Freight or any other breach of the obligations to its charge included in the Xxxx of Lading, due to an act of God or Force Majeure, which include without limitation lightning, hurricanes, earthquakes, land sliding, violence, war, insurrections, derailing, obstructions to tracks, acts of authority, fires, floods, acts of terrorism, strikes, demonstrations or any other circumstance beyond its control and not attributable to KCSM. Likewise, KCSM will be released of all liability in case the User fails to inspect the Railroad Equipment assigned prior to be loaded, and in such case no claim or lawsuit filed for such concepts shall proceed.
Acts of God or Force Majeure. It is expressly understood that the BENEFICIARY shall not be liable for the delay or total or partial non-fulfillment of its obligations, consisting in the performance of the exploration works in terms of this document, as well as of making the payments referred to in section 4 of Clause Second of these Contracts, when such delay or non-fulfillment results from an Act of God or force majeure, this is, from facts or events of nature or man that are unforeseeable or that even in the case they might be foreseen, they cannot be avoided by the BENEFICIARY. In accordance with that indicated in the above paragraph, the parties agree that the events mentioned below, as examples but not in a limitative manner, shall be considered as acts of God or force majeure: accidents such as fire, explosions, flooding, tempests, tremors, epidemics, civil disturbances, labor disturbances, strikes, wars, invasions, oppositions or disturbances caused by rural communities, ejido's communities or any other kind of association legally created or not, as well as oppositions or disturbances caused by any other person impeding the free access of the BENEFICIARY to the LOT or obstructing the performance of the mining works set forth in this Contract, as well as actions or omissions of any governmental authority, whether Federal, State or Municipal, which include the delay or impossibility to timely obtain such permits required from any governmental authority, individual or corporation, group or entity to carry out the mining works provided for in this document. The aforecited events shall be considered as acts of God or force majeure, as the case may be, if in the event of occurrence they obstruct or delay, whether totally or partially, the fulfillment of the obligations of the BENEFICIARY, if and when such event is not provoked by an action or omission imputable to the BENEFICIARY itself. In the event that an occurrence take place causing an act of God or force majeure, the BENEFICIARY shall notify it to the TITLEHOLDERS within a term of 30 (thirty) calendar days, counted from the date on which the BENEFICIARY becomes aware of such event. If the act of God or force majeure continues, the term to carry out the works of exploration shall be extended for a term equal to the duration of the act of God or force majeure, in order for the term of the exploration to be of one effective year.
Acts of God or Force Majeure events of acts of God or force majeure, as defined in article 393 of the Brazilian Civil Code, examples of which are indicated in item 2.7.3. (List of Examples of Acts of God or Force Majeure) below (“Acts of God or Force Majeure”);
Acts of God or Force Majeure. The existence of an act of God or force majeure as provided for under Argentine law shall release the parties from all responsibility for the obligations they have assumed, absent an express reservation to the contrary.
Acts of God or Force Majeure. The parties shall not be considered in non-compliance when by any Act of God or force majeure any of them is unable to comply with the obligations agreed herein. The following causes shall be considered as force majeure, in an enunciatively but not limited manner: earthquakes, fires, floods, landslides, collapse, demonstrations, wars, strikes, revolutions, acts of authority, mobs, revolts, and, in general, any other act totally out of control from the parties that might prevent them to comply with any of their obligations, totally or partially. When any of the parties becomes affected by any force majeure, and thus unable to comply with its obligations, a written notification should be sent to the other party, reporting the estimated time of such incapability to comply with them. When six months have elapsed from the date a force majeure has occurred and it still persists, the other party shall have the right to terminate this Contract.
Acts of God or Force Majeure. 12.1 Any default or delay in its responsibilities regarding equipment installation, beginning or continuation of services provided by IMPSAT will not generate any liabilities against IMPSAT if such default or delay should result from acts of God or force majeure, being these understood as acts or facts of the government, natural phenomena, or any other circumstances outside IMPSAT's control, including, but not limiting to adverse conditions, whether meteorological or astronomical, communication provider going out of service for whatever reason, either partially or totally, temporarily or definitely, earthquakes, epidemics, civil riots, fires, strikes, war, acts or omissions of the satellite owner.
Acts of God or Force Majeure. División El Xxxxxxxx will not indemnify MVC in the event the latter is unable to operate its treatment plant due to acts of God or force majeure affecting DET. Likewise, MVC will not be required to make any payment or provide any indemnification in favor of DET due to any acts of God or force majeure affecting MVC. Acts of God or force majeure are understood to be an unforeseen and irresistible event, on the terms set out in article 45 of the Chilean Civil Code, and those expressly set out in this Agreement. Notwithstanding the foregoing, by way of example and in addition, as the case may be, the following circumstances will be understood to constitute acts of God and force majeure, provided they prevent the continued operation of the production process and on the conditions indicated below:
Acts of God or Force Majeure. (A) The Participants' obligations, except the obligations to pay or distribute profits when its distribution has been resolved as stipulated herein and to make other payments or contributions pursuant to this contract, shall be suspended to the extent and during the time in which they cannot be fulfilled by acts of God or by force majeure or because of any other event beyond its control, foreseeable or unforeseeable, including, but without limitation, (i) fires, explosions, earthquakes, hurricanes, storms, floods, sink holes, draughts, or other adverse environmental conditions; (ii) wars, declared or undeclared, rebellions, terrorist actions, guerrillas, social commotions, coup d'etats, insurrections, and invasions; (iii) strikes, work stoppages, or other analogous labor conflicts, taking of facilities, obstructions, agrarian intrusions, and actions or omissions of indigenous groups, non-governmental or environmental organizations or of similar-interests organizations; (iv) acts or omissions of authorities, judgments or other kinds of judicial rulings, inability to obtain permits, consents, licenses, concessions, authorizations, approvals, and opinions; (v) delays or failures to comply of providers or transporters, contractors, or subcontractors; (vi) shortage or inability to obtain labor, transportation, materials, machinery, equipment, supplies, utilities or services; (vii) accidents; breakdown of equipment, machinery or facilities; and (viii) other events of analogous or similar nature.
Acts of God or Force Majeure. 14.1 The legal scope and effects provided in the Argentine Civil Code, the Buyer's Service Rules, TGS Regulations as well as the legal effects of any Acts of God or Force Majeure provided in the following situations shall apply:
Acts of God or Force Majeure. The contracting parties acknowledge that there will be no liability of the parties if this agreement is breached due to Acts of God or force majeure; however, if during the term of this document any damage to the vehicle is caused by these same assumptions, the lessee shall notify the Car Rental Company and the competent authorities as soon as possible and shall not exceed 48 hours after becoming aware of the fact. The delay in the notice will be considered as a breach of this agreement, so the lessee will be responsible for compensating the damages that the Car Rental Company has suffered due to said damage". | 14. Forgotten items in the rented vehicle. At the time of return of the rented vehicle, lessee shall verify that there are no personal belongings in the vehicle, otherwise the Car Rental Company will not be responsible for the belongings left in the vehicle, nor for the damage or demerit that could be caused when being transported inside the same vehicle. | 15.
