ACCEPTANCE AND FINAL PAYMENT. Final payment may be requested by the Contractor upon completion and acceptance, by the Town, of all work as set forth in the Contract Documents. The total amount of final payment shall consist of the Contract Price, as adjusted in accordance with approved change orders, if applicable, less all previous payments to the Contractor.
ACCEPTANCE AND FINAL PAYMENT. When the contract work has been accepted in accordance with the requirements of the subsection titled FINAL ACCEPTANCE of Section 50, the Engineer will prepare the final estimate of the items of work actually performed. The Contractor shall approve the Engineer's final estimate or advise the Engineer of his/her objections to the final estimate which are based on disputes in measurements or computations of the final quantities to be paid under the contract as amended by change order or supplemental agreement. The Contractor and the Engineer shall resolve all disputes (if any) in the measurement and computation of final quantities to be paid within 30 calendar days of the Contractor's receipt of the Engineer's final estimate. If, after such 30-day period, a dispute still exists, the Contractor may approve the Engineer's estimate under protest of the quantities in dispute, and such disputed quantities shall be considered by the Owner as a claim in accordance with the subsection titled CLAIMS FOR ADJUSTMENT AND DISPUTES of Section 50. After the Contractor has approved, or approved under protest, the Engineer's final estimate, final payment will be processed based on the entire sum, or the undisputed sum in case of approval under protest, determined to be due the Contractor less all previous payments and all amounts to be deducted under the provisions of the contract. All prior partial estimates and payments shall be subject to correction in the final estimate and payment. If the Contractor has filed a claim for additional compensation under the provisions of the subsection titled CLAIMS FOR ADJUSTMENTS AND DISPUTES of Section 50 or under the provisions of this subsection, such claims will be considered by the Owner in accordance with local laws or ordinances. Upon final adjudication of such claims, any additional payment determined to be due the Contractor will be paid pursuant to a supplemental final estimate. Neither the Final Payment nor the remaining retained percentage shall become due until the Contractor submits to the OWNER
ACCEPTANCE AND FINAL PAYMENT. When the work performed under this agreement has been fully completed in accordance with the Specifications provided a final inspection shall be made by the CITY and any defects arising out of said inspections shall be remedied by the CONTRACTOR. Retainage shall be paid by the CITY upon submittal by the CONTRACTOR of lien waivers, certified payrolls, and affidavit of compliance with prevailing wage laws. Final payment and acceptance of such payment by the CONTRACTOR shall release the CITY from all claims of any liabilities of the CONTRACTOR under this agreement, except that the CONTRACTOR shall not be released from liability for defects resulting from unacceptable workmanship or failure to follow Specifications, where said defects are not readily ascertainable by the CITY upon final inspection. The CITY shall make final payment upon the CONTRACTOR’s submittal of lien waivers, certified payrolls, and affidavit of compliance with prevailing wage laws.
ACCEPTANCE AND FINAL PAYMENT. When the Contractor has completed the work in accordance with the terms of the Contract Document, he shall certify completion of the work to the Owner and submit a final Request for Payment, which shall be the Contract Amount plus all approved additions, less all approved deductions and less previous payments made. The Contractor shall furnish evidence that he has fully paid all debts for labor, materials, and equipment incurred in connection with the work, and upon acceptance by the Owner, the Owner will release the Contractor, any legal rights of the Owner, required guaranties, and will pay the Contractor's final Request for Payment.
ACCEPTANCE AND FINAL PAYMENT. Final payment less amounts withheld to cover the cost of nonconforming work, shall be made by the Owner in accordance with General Conditions Article 10.7.
ACCEPTANCE AND FINAL PAYMENT. Final payment shall be made after final acceptance of the Work, provided the Work is fully completed and the Contract fully performed as provided in the UGSC.
ACCEPTANCE AND FINAL PAYMENT. When the contractor shall have completed the work in accordance with the terms of the contract documents, the Engineer shall certify his (her) acceptance to the owner and his (her) approval of the contractor's final request for payment, which shall be the contract amount plus all approved additions less all approved deductions (including retention) and less previous payments made. The request for final payment shall be made on the form contained in these specifications. The contractor shall furnish evidence that they have fully paid all debts for labor, material, and equipment incurred in connection with the work, following which the owner shall accept the work and release the contractor except as to the conditions of the performance bond, any legal rights of the owner, required guarantees, and corrections of faulty work after final payment, and shall authorize payment of the contractor's final request for payments per the Contract Agreement. The contractor must allow sufficient time between the time of completion of the work and approval of the final request for payment for the Engineer to assemble and check the necessary data.
ACCEPTANCE AND FINAL PAYMENT. The Contractor shall submit to the City a sworn affidavit that all bills for labor, service, materials, and subcontractors have been paid and that there are no suits pending in connection with the work done or labor and materials furnished under the Contract. All prior certificates and estimates, being approximate only, are subject to correction in the final estimate and payment. The Contractor with this contract hereby warrants all of the work done under this contract for a period of one (1) year following the completion of the project. Upon completion, the Contractor shall submit to the City a written one (1) year warranty on total project. Failure of the Contractor to submit a written warranty does not release the Contractor of this warranty in any way. If, after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor, the City shall upon certificate without terminating the Contract, make payment of the balance due for that portion of the work fully completed and accepted. Such payment shall be made under the terms and conditions covering final payment, and it shall not constitute a waiver of claims by the City.
ACCEPTANCE AND FINAL PAYMENT. 22.1 Upon receipt of written notice from the CONTRACTOR that the work is ready for final inspection and acceptance, the CITY shall within ten days make an inspection thereof. If the CITY finds the work acceptable under the Contract and the Contract work has been fully performed, payment shall be issued by the CITY, stating that the work required by the Contract has been completed and is accepted under the terms and conditions thereof.
ACCEPTANCE AND FINAL PAYMENT. Upon receipt of written notice that the work is ready for final inspection and acceptance, the Engineer or Architect shall promptly make such inspection, and when he/she finds the work acceptable under the contract fully performed he/she shall promptly issue a final certificate, over his/her own signature, stating that the work provided for in this contract has been completed and is accepted under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained percentage, shall be paid to the Contractor within (30) days after the execution of said final certificate.
