Delay Payments definition

Delay Payments means the amounts payable by the Supplier to the Customer in respect of a delay in respect of a Milestone as specified in the Implementation Plan;

Delay Payments means payments detailed in paragraph 4.1 of the Order Form;

Delay Payments means any breach of the obligations of the Supplier (including but not limited to fundamental breach or breach of a fundamental term) or any other default, act, omission, negligence or negligent statement of the Supplier or the Supplier’s Staff in connection with or in relation to the subject-matter of this Contract and in respect of which the Supplier is liable to the Customer; means payments detailed in paragraph 5.1 of the Order Form;

Examples of Delay Payments in a sentence

• Similarly, if a Bidder feels that any important provisions in the documents, such as Governing laws, Taxes and Duties, Defect Liability, Limitation of Liability, Settlement of Disputes, Arbitration, Form of Contact Agreement, Price Adjustment, Bid Guarantees, Contract Performance Guarantee, Compensation for Delay, Payments Terms, Schedule of Execution/Completion of works, will be unacceptable, such an issue should be raised as above.

• Changes to the Milestones (if any), Milestone Payments (if any) and Delay Payments (if any) shall only be made in accordance with the Variation Procedure and provided that the Supplier shall not attempt to postpone any of the Milestones using the Variation Procedure or otherwise (except in the event of a Customer Cause which affects the Supplier's ability to achieve a Milestone by the relevant Milestone Date).

• See also Clause 6.4 in relation to Delay Payments and refine the Delay Payment provisions if needed.

• Under Clause 6.4.1(b)(ii) the Customer shall have additional remedies for delay (over and above the Delay Payments) where the delay exceeds the time specified above for the Delay Period Limit.

• The Delay Payments will accrue on a daily basis from the relevant Milestone Date and will continue to accrue until the date when the Milestone is achieved.

More Definitions of Delay Payments

Delay Payments the amounts payable by the Supplier to the Authority in respect of a Delay in Achieving a Key Milestone as specified in Schedule 7.1 (Charges and Invoicing);

Delay Payments means the payments due to the Customer from the Supplier in accordance with paragraph 4 of the Order Form;

Delay Payments means the amounts payable by the Supplier to the Authority in respect of a delay in respect of a Milestone as specified in the Implementation Plan;

Delay Payments shall have the meaning set forth in the Preamble.

Delay Payments means the amounts payable by the Supplier to the

Delay Payments means the amounts payable by the Contractor to the DCC in respect of a Delay as specified in Schedule 7.1 (Charges and Payment);

Delay Payments has the meaning specified in Section 11.04.