Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Unreasonably impracticable means that the measures necessary to comply with the regulations require such a high investment of risk, money, time, or any other resource or asset that the operation of a marijuana establishment is not worthy of being carried out in practice by a reasonably prudent businessperson.
Reasonable Distance means a distance that has regard to the Employee’s original work location, current home address, capacity of the Employee to travel, additional travelling time, effects on the personal circumstances of the affected Employee, including family commitments and responsibilities and other matters raised by the Employee, or assistance provided by their Employer.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Reasonable Commercial Efforts means, with respect to the applicable obligation of the Company, reasonable commercial efforts for similarly situated, publicly-traded companies.
Written Testing-the-Waters Communication means any Testing-the-Waters Communication that is a written communication within the meaning of Rule 405 under the Securities Act.
Reasonable notice means, at a minimum:
Testing-the-Waters Communication means any oral or written communication with potential investors undertaken in reliance on Section 5(d) of the Securities Act.
CAFRA Centers, Cores or Nodes means those areas with boundaries incorporated by reference or revised by the Department in accordance with N.J.A.C. 7:7-13.16.
Additional Work to mean additions or deletions or modifications to the amount, type or value of the Work and Services as required in this Contract, as directed and/or approved by the County.
Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.
Unreasonable adverse effects on the environment means any unreasonable risk to humans or the environment, taking into account the economic, social, and environmental costs and benefits of the use of any pesticide.
Reasonable cause as used in this policy means an articulable belief based on specific facts and reasonable inferences drawn from those facts that an employee is more likely than not under the influence of controlled substances or alcohol or has used drugs or alcohol in violation of this policy. Circumstances which can constitute a basis for determining "reasonable cause" may include, but are not limited to:
Reasonable further progress means such annual incremental reductions in emissions of the relevant air pollutant as are required by the applicable implementation plan or may reasonably be required by the Director for the purpose of ensuring attainment of the applicable ambient air quality standard by the applicable date.
reasonable possibility means that there is a cause and effect relationship between the investigational product, study device and/or study procedure and the AE.
Contracting activity for DoD also means elements designated by the director of a defense agency which has been delegated contracting authority through its agency charter. DoD contracting activities are listed at PGI 202.101.
Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.
Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);
Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and
Concurrent Users means the number of users registered in the Software who are able to use the Software functionalities at the same time.
Force Majeure Period has the meaning specified in Section 13.1.
Reasonable grounds means that a reasonable person in your position would also suspect the information indicates misconduct or a breach of the law.