Material Project Document means (i) any contract or agreement that is related to the ownership, operation, maintenance, management service, repair or use of the System entered into by the Company or any Subsidiary subsequent to the Third Amendment Date that involves full payments or obligations of the Company or any Subsidiary in excess of $5,000,000 in any calendar year, and (ii) System Leases, but shall exclude any documents subject to Section 10.12 herein.
Material Project Document means any of the Prime Construction Contract, the Golf Course Construction Contract, the Parking Structure Construction Contract, the Professional Design Services Agreements, the Construction Guaranty, the Water Supply Contract, the Affiliate Real Estate Agreements, and, without duplication, any Project Document with a total contract amount in excess of $5,000,000 and each Payment and Performance Bond issued to support any of the foregoing.
Material Project Document means each of the agreements listed on Schedule 5.12(b), any Additional Project Document that replaces any of the foregoing, the System Lease and the Contribution Agreement.
Examples of Material Project Document in a sentence
Material Project Agreements Certain documents referenced in the Credit Agreement: Each Material Project Document (as defined in the Credit Agreement) Certain other documents: Nil.
Additional Proj ect Documents” means any contracts or agreements entered into by Borrower, or assigned to Borrower, that (i) replaces or substitutes for an existing Material Project Document, (ii) meets the criteria set forth in clause (b) of the definition of “Material Project Document,” or (iii) has a value over its term in excess of One Million Dollars ($1,000,000).
No later than the third Business Day following the date of receipt by any Loan Party of any termination payment or liquidated damages paid by a Material Project Party under a Material Project Document in excess of $100,000,000, the Borrower shall prepay the Loans as set forth in Section 2.12(b) in an aggregate amount equal to such payment.
Copies of all material written notices or material written periodic reports received by the Borrower or any of its Subsidiaries under any Material Project Document it is a party to.
To Borrowers’ Knowledge, no other party to any Material Project Document is in default of its obligations thereunder.
More Definitions of Material Project Document
Material Project Document means each project document that is, in the Borrower’s good-faith business judgment, material and required to develop, procure, construct, commission and operate the Project, and shall in any event include the EAF Supply Agreement, all material construction contracts related to the construction of the Project and all material construction contracts related to the Electrification Completion.
Material Project Document means any Project Document for a Material Project.
Material Project Document means each Project Document relating to the ownership, management, development, use, leasing, maintenance, repair or improvement of the Project Assets under which there is an obligation of an Obligor, in the aggregate, to pay, or under which any Obligor receives in compensation more than, $100,000 per annum, excluding any agreement which is terminable by an Obligor on not more than sixty (60) days’ prior written notice without any fee or penalty.
Material Project Document means (a) each of the contracts or other arrangements to which the Borrower or any of the Project Companies is a party (other than the Loan Documents) (i) set forth on schedule 4.15 of the Senior Credit Agreement and (ii) entered into after the Closing Date, in each case, for which breach, nonperformance, cancellation or failure to renew could reasonably be expected to have a Material Adverse Effect and (b) any Project equity commitment letters, letters of intent relating to Project equity or other similar arrangements (i) set forth on schedule 4.15 of the Senior Credit Agreement and (ii) entered into after the Closing Date.
Material Project Document means (i) each Project Document that is or will be necessary or advisable for the Borrower Parties to enter into in order to acquire, import, own, construct, install, operate, insure or maintain the Project or any material portion of the Project (other than services, materials or rights that can reasonably be expected to be readily available on commercially reasonable terms), (ii) each Project Document that is or will be necessary or advisable for the Borrower Parties to enter into in order for such Borrower Party to obtain, maintain in full force and effect or comply with any other Material Project Document, any Material Permit or any material applicable Law, (iii) each Project Document that is or will be necessary or advisable for the Borrower Parties to enter into in order to maintain their respective business generally or to maintain their respective existence, (iv) without limiting the foregoing (other than the parenthetical set forth in subclause (i) of this definition), each Project Document where (A) the aggregate cost or value of goods and services to be acquired by any Borrower Party pursuant thereto could reasonably be expected to exceed $2,000,000 or the equivalent in any other currency in any year, (B) the aggregate amount of termination fees or liquidated damages which could be incurred by any Borrower Party in respect of such Additional Project Document in any single year could reasonably be expected to exceed $2,000,000 or the equivalent in any other currency or (C) such Project Document provides for the sale of any goods, services, capacity, or other right, title or interest in any Property of any Borrower Party (other than Dispositions permitted in accordance with Section 7.20) and (v) without limiting the foregoing, any and all EPC Contracts and the Environmental Indemnity.
Material Project Document means the PPAs, the Geothermal Leases, the Interconnection Agreements, the O&M Agreements, the Recapture Indemnity Agreement, the Holy Cross Purchase and Sale Agreement, the Public Utility District Purchase and Sale Agreement and any other documents listed on Schedule 5.12(a) , and any agreement that replaces any of the foregoing.
Material Project Document means, with respect to each Company, (a) any contract to which such Company is a party, or by the terms of which such Company or its Assets are bound; (b) any interconnection or transmission-related agreements or applications for interconnection or transmission of or from the Company’s Project; (c) any contract providing for any Indebtedness of such Company or the mortgaging, pledging or otherwise placing a Lien on any Assets of such Company, or the guarantying of any obligation (other than endorsements made for collection) or that is otherwise related to any such Indebtedness; (d) all employment, severance or change in control agreements binding upon such Company; and (e) any Real Property Document.