Date for Completion means the date for Completion specified in the Contract Specifics.
Date for Completion has the meaning given in the Sale Contract.
Date for Completion. The date set out in paragraph 6 of the Form of Agreement. Unless the Authority has not received a final report as set out in paragraph 4 of the Reports Schedule, in which case the Completion Date shall be the date on which the Authority receives such a report.
Examples of Date for Completion in a sentence
Any amendment to the Date for Completion is the Contractor’s sole remedy for any delays resulting from Force Majeure where the Contractor is the affected party and the Contractor is not entitled to any increase in the Price or any damages, costs or expenses in connection with the Force Majeure.
The sum stated as liquidated damages under the Special Conditions must be paid by the Contractor to the Principal for the period between the Due Date for Completion and the actual date of Practical Completion.
The Contractor must achieve Practical Completion by the Due Date for Completion.
More Definitions of Date for Completion
Date for Completion means the date for Completion specified in the Contract Details.
Date for Completion means the date for the completion of the Services or any part of the Services specified in Item 4 of the Key Terms Schedule or if no such item is specified in the Key Terms Schedule, the equivalent item in the Purchase Order, or elsewhere in this Contract (including an Approved Services Program), or if none is specified, the date upon which the parties intend the Services or that part of the Services to be completed;
Date for Completion means the date for completion of the Sub-Contract Works or a Section (as appropriate) specified in the Sub-Contract Order or if no date is specified in the Sub-Contract Order the date that is a reasonable period of time after the Commencement Date taking account of the nature of the Sub-Contract
Date for Completion means the date specified in item 5 of Appendix A as extended by such period agreed or determined in accordance with clauses 23.6 and 25;
Date for Completion means the date set out in the Agreement or otherwise specified by Nokia for the Completion.
Date for Completion means the date or dates specified in the Quotation or otherwise agreed in writing between the Buyer and the Seller on which the Goods are to be delivered and/or services completed at the Place of Delivery, including for the avoidance of doubt, any extension to the Date for Completion arising from any delay, or determined in accordance with the Contract.
Date for Completion means in respect of the Works or a Portion the date, or the last day of the period of time, specified in Schedule 1 for the Works or that Portion, as adjusted under this Contract by an extension of time determined by the Principal's Representative or pursuant to any determination by an expert or any arbitration pursuant to clause 15.