Complete Destruction definition

Complete Destruction or “Completely Destroy” shall mean to cause the expiration of a controlled substance at a destruction efficiency of 98 percent or greater, using one of the destruction technologies approved by the Parties to the Montreal Protocol, or as defined in 40 C.F.R. § 82.3;
Sample 1Sample 2Sample 3
Complete Destruction means the destruction of or damage to any portion of the Operated Facilities situated in a separate building or separate building complex where the gross leasable area subject to the damage or destruction is more than twenty-five percent (25%) of the gross leasable area of the portion of the Operated Facilities situated in such building or building complex;
Sample 1Sample 2
Complete Destruction means the destruction of or damage to the Hotel resulting from fire, casualty or any other cause whereby the destruction of or damage to the Hotel is such that the Replacement Value reasonably estimated by Owner is greater than $7,500,000.
Sample 1

Examples of Complete Destruction in a sentence

  • In each semi-annual report required under Paragraph 38 of this Consent Decree, Defendant shall provide EPA with all receipts, invoices, and other documentation demonstrating the Complete Destruction of R-12 Refrigerant, including dates of destruction and, for each date of destruction, the quantity destroyed, method of destruction, and name and address of the Destruction Facility.

  • The state space, A, for ∈∈ ∈this problem would consist of all possible combinations of the attributes of the trucker.

  • OPCW Director-General Praises Complete Destruction of Libya’s Chemical Weapon Stockpile,” OPCW Press Release, January 11, 2018.

  • Rents payable for the leased areas in the Terminal Building and/or Ready/Return Block will only abate if the City/Airport Company is unable to provide alternative space for Concessionaire to conduct its business.Subsection 15.3 Complete Destruction.

  • It will also not lead to any penalty or loss of benefits that you would have outside of the research study.

  • This principle is so clear in Florida jurisprudence that on June 6, 2013, the Florida Supreme Court adopted Standard Jury Instructions for Breach of Contract Damages: 504.3 Lost Profits and 504.4 Damages for Complete Destruction of Business.

  • Illustration 2: Complete Destruction When Basis Exceeds Value 323¶ 18.2423.

  • Illustration 2: Complete Destruction When Basis Exceeds Value 335¶ 17.2423.

  • Again, however, we do not find a definitive and systematic relationship on this issue across the studies in our sample, perhaps in part due to the diversity of studies (see Figure 6).

  • Complete Destruction of all the existing Termitariums present in site and destruction of the queen from Termitariums.c).


More Definitions of Complete Destruction

Complete Destruction. The destruction of or material damage to any US Commercial Properties situated in a separate building or separate building complex where the gross leasable area subject to such material damage or destruction is more than twenty-five percent (25%) of the gross leasable area of all of the US Commercial Properties situated in such building or building complex.
Sample 1
Complete Destruction if the Building is damaged or destroyed by fire or other cause to such an extent that the cost of repair and restoration of the Building exceeds 30% of the amount it would cost to replace the Building in its entirety at the time such damage or destruction took place. The opinion of an architect or registered engineer selected by Landlord as to the costs of such repair, restoration or replacement shall be controlling upon both Landlord and Tenant. "Cost Saving Installation" — a labor saving device, energy savings device or other installation, improvement or replacement which is installed or made primarily for the purpose of reducing Operating Costs, whether or not voluntary or required by government mandate.
Sample 1
Complete Destruction means the damage or destruction of any structure by any means whatsoever to the extent that, in the judgement of the Division, 75% or more of the original structure, or if a building, more than 50% of the original foundation pilings, are unsuitable for incorporation into reconstruction of the structureComment [JLL16]: Required by Act change
Sample 1
Complete Destruction if the Leased Premises or Building should be damaged or destroyed by any cause to such an extent that insurance does not cover and:
Sample 1

Related to Complete Destruction

  • Premises Total Destruction means damage or destruction to the Premises, other than Lessee Owned Alterations and Utility Installations and Trade Fixtures, which cannot reasonably be repaired in six (6) months or less from the date of the damage or destruction. Lessor shall notify Lessee in writing within thirty (30) days from the date of the damage or destruction as to whether or not the damage is Partial or Total.

  • Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Leasehold Improvements means all buildings, structures, improvements and fixtures located on any Leased Real Property which are owned by Company or any Company Subsidiary, regardless of whether title to such buildings, structures, improvements or fixtures are subject to reversion to the landlord or other third party upon the expiration or termination of the lease for such Leased Real Property.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Complete Termination means a termination of the Fund's Rule 12b-1 plan for B-2 Shares involving the cessation of payments of the Distribution Fees, and the cessation of payments of distribution fees pursuant to every other Rule 12b-1 plan of the Fund for every existing or future B-Class-of-Shares (as hereinafter defined) and the Fund's discontinuance of the offering of every existing or future B-Class-of-Shares, which conditions shall be deemed satisfied when they are first complied with hereafter and so long thereafter as they are complied with prior to the earlier of (i) the date upon which all of the B-2 Shares which are Distributor Shares pursuant to Schedule I hereto shall have been redeemed or converted or (ii) May 31, 2005. For purposes of this Section 14.5, the term B-Class-of-Shares means each of the B-1 Class of Shares of the Fund, the B-2 Class of Shares of the Fund and each other class of shares of the Fund hereafter issued which would be treated as Shares under Schedule I hereto or which has substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of the shares of such class. The parties agree that the existing C Class of Shares of the Fund does not have substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares. For purposes of clarity the parties to this agreement hereby state that they intend that a new installment load class of shares which may be authorized by amendments to Rule 6(c)-10 under the 1940 Act will be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing B-1 or B-2 Classes of Shares taking into account the total sale charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares and will not be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing C Class of shares of the Fund taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares.

  • Substantial improvement means any combination of repairs, reconstruction, rehabilitation, addition, or other improvement of a structure, taking place during any one-year period for which the cost equals or exceeds 50 percent of the market value of the structure before the “start of construction” of the improvement. This term includes structures which have incurred “substantial damage”, regardless of the actual repair work performed. The term does not, however, include either:

  • Premises Building Partial Damage shall herein mean damage or destruction to the building of which the Premises are a part to the extent that the cost of repair is less than 50% of the then replacement cost of such building as a whole.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Premises Partial Damage means damage or destruction to the improvements on the Premises, other than Lessee Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than 50% of the then Replacement Cost of the Premises immediately prior to such damage or destruction, excluding from such calculation the value of the land and Lessee Owned Alterations and Utility Installations.

  • Premises means the location where the Services are to be supplied, as set out in the Specification.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • aerial work means an aircraft operation in which an aircraft is used for specialised services such as agriculture, construction, photography, surveying, observation and patrol, search and rescue, and aerial advertisement;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Untenantable means that Tenant shall be unable to occupy and shall not be occupying the Premises or the applicable portion thereof for the conduct of business ordinarily conducted in the Premises as a result of the Casualty.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Substantial Taking means a Taking of at least 15% of the Land or Improvements which, in Lessee’s and Lessor’s reasonable judgment, will materially and adversely interfere with any development or use of the Premises that Lessee is then conducting or intends in good faith to conduct in the future.

  • Substitute Improvements means the substitute or additional improvements of the Issuer described in Article V hereof.

  • Permanent radiographic installation means an enclosed shielded room, cell, or vault, not located at a temporary jobsite, in which radiography is performed.

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).