TRENCH SAFETY ACT. Pursuant to Chapter 90-96 (CS/SB 2626), Laws of Florida, "Trench Safety Act", any person submitting a Bid/proposal is required to complete the form entitled: COMPLIANCE WITH FLORIDA TRENCH SAFETY ACT (90-96, LAWS OF FLORIDA), if applicable, and return the form with the Official Bid Form, (Part D, Attachment D) This is not a pay item. The purpose of this form is to gather information on the costs associated with trench safety measures and to insure that the Bidder has considered these costs and included them in the Base Bid. Failure to complete this form may result in the Bid being declared non-responsive.
TRENCH SAFETY ACT. Pursuant to Chapter 90-96 (CS/SB 2626), Laws of Florida, "Trench Safety Act", any person submitting a Bid is required to comply with FLORIDA TRENCH SAFETY ACT (90-96, LAWS OF FLORIDA), if applicable only. This is not a pay item. The purpose of this form is to gather information on the costs associated with trench safety measures and to insure that the Respondent has considered these costs and included them in the Base Bid. If this form is applicable, failure to complete this form may result in the Bid being declared non-responsive. If applicable, Respondents shall submit this form as an attachment. The Compliance with Florida Trench Safety Act Form can be found at on the County's Forms and Resources website (xxxxx://xxx.xxxx.xxx/vfr).
TRENCH SAFETY ACT. The Total Program Manager must comply with the provisions of the Trench Safety Act (Florida Statutes Section 553.63, 1998). EXHIBIT A CONSTRUCTION TEAM ASSIGNED REPRESENTATIVES Owner Superintendent of Schools Deputy Superintendent for Facilities and Construction Management Project Manager Total Program Manager ((Off Site I)) ((Title I)) ((Off Site 2)) ((Title 2)) ((Off Site3)) ((Title 3)) ((OffSite4)) ((Title 4)) ((OffSite5)) ((Title 5)) ((OffSite6)) ((Title 6)) ((Onsite 1)) ((Title l )) ((OnSite2)) ((Title 2 )) ((OnSite3)) ((Title 3 )) ((On S ite5)) ((Title 5 )) EXHIBIT B OWNER’S CONSTRUCTION BUDGET ITEM DESCRIPTION CONSTRUCTION BUDGET ESTIMATED COST OF WORK (( )) TOTAL PROGRAM MANAGER’S PRE-DESIGN PHASE FEE ((PreDesignPhaseFee)) TOTAL PROGRAM MANAGER’S DESIGN PHASE FEE ((DesignPhaseFee)) TOTAL PROGRAM MANAGER’S BIDDING AND AWARD PHASE FEE ((Bidding & Award Fee)) TOTAL PROGRAM MANAGER’S CONSTRUCTION PHASE FEE ((ConPhaseFee)) TOTAL PROGRAM MANAGER’S WARRANTY PHASE FEE ((Oamt)) TOTAL PROGRAM MANAGER’S OVERHEAD ((Wamt)) TOTAL PROGRAM MANAGER’S PROFIT ((Pamt)) TOTAL PROGRAM MANAGER’S GENERAL CONDITIONS ((GC Fee)) TOTAL PROGRAM MANAGER’S TOTAL FEES (( )) OWNER’S TOTAL CONSTRUCTION BUDGET (FLCC) ((FLCC)) EXHIBIT C TOTAL PROGRAM MANAGERS PERSONNEL OFF-SITE SUPPORT STAFF Individual Title ((OffSite 1+ ((Title 1)) ((OffSite2+ ((Title2)) ((OffS ite3+ ((Title3)) ((OffSite4>) ((TItle4)) ((OffS ite5+ ((Title5)) ((OffS ite6+ ((Title6)) ON-SITE SUPPORT STAFF Individual Title ((ONSITE 1)) ((Titlel 1)) ((OnSite2)) ((Title2 )) ((OnSite3)) ((Title3 )) ((OnSite4)) ((Title4 )) ((OnS ite5)) ((Title5 )) ((TO Be Assigned)) EXHIBIT D
TRENCH SAFETY ACT. Pursuant to Chapter 90-96 (CS/SB 2626), Laws of Florida, "Trench Safety Act", any person submitting a Bid is required to comply with the requirements of the FLORIDA TRENCH SAFETY ACT (90-96, LAWS OF FLORIDA). The Contractor must complete the Trench Safety Act Form (“Form”) and return the Form with its Proposal. Failure to submit said Form will result in the Contractor being deemed non-responsive. The Town in its sole discretion may allow the Form to be submitted during the evaluation process. Any costs identified on the Form are not a pay item. The purpose of this form is to gather information on the costs associated with trench safety measures and to insure that the Bidder has considered these costs and included them in its Bid prices. Failure to complete this form may result in the Bid being declared non-responsive.
TRENCH SAFETY ACT. Contractor certifies that it does, and shall, comply with the Trench Safety Act (Chapter 553, Florida Statutes).
TRENCH SAFETY ACT. (Construction) Offerors shall comply with the “Florida Trench Safety Act”. WASTE TIRE RECYCLING/DISPOSAL SCOPE OF WORK Specification: Annual Fixed Price Contract for Waste Tire Removal and Recycling/Disposal from the Escambia County Waste Service (WS) Waste Tire Collection Center (WTCC) located at 00000 Xxxxxx Xxxx, Cantonment, Florida. Service will be provided on a weekly basis.
