Surrender of the Premises Upon the expiration or sooner termination of this Lease, Tenant shall vacate and surrender the Premises to Landlord in the same condition as existed at the Commencement Date, except for (i) reasonable wear and tear, (ii) damage caused by any peril or condemnation, and (iii) contamination by Hazardous Materials for which Tenant is not responsible pursuant to Section 7.2A or Section 7.2B. In this regard, normal wear and tear shall be construed to mean wear and tear caused to the Premises by the natural aging process which occurs in spite of prudent application of the best standards for maintenance, repair and janitorial practices, and does not include items of neglected or deferred maintenance. In any event, Tenant shall cause the following to be done prior to the expiration or the sooner termination of this Lease: (i) all interior walls shall be painted or cleaned so that they appear freshly painted; (ii) all tiled floors shall be cleaned and waxed; (iii) all carpets shall be cleaned and shampooed; (iv) all broken, marred, stained or nonconforming acoustical ceiling tiles shall be replaced; (v) all interior and exterior windows shall be washed; (vi) the HVAC system shall be serviced by a reputable and licensed service firm and left in good operating condition and repair as so certified by such firm; and (vii) the plumbing and electrical systems and lighting shall be placed in good order and repair (including replacement of any burned out, discolored or broken light bulbs, ballasts, or lenses). If Landlord so requests, Tenant shall, prior to the expiration or sooner termination of this Lease, (i) remove any Tenant’s Alterations which Tenant is required to remove pursuant to Section 5.2 and repair all damage caused by such removal. If the Premises are not so surrendered at the termination of this Lease, Tenant shall continue to be responsible for the payment of Rent until the Premises are so surrendered in accordance with said provisions and Tenant shall be liable to Landlord for all costs incurred by Landlord in returning the Premises to the required condition, plus interest on all costs incurred at the Agreed Interest Rate. Tenant shall indemnify Landlord against loss or liability resulting from delay by Tenant in so surrendering the Premises, including, without limitation, any claims made by any succeeding tenant or losses to Landlord due to lost opportunities to lease to succeeding tenants and losses and damages suffered by Landlord due to lost opportunities to lease any portion of the Premises to any such succeeding tenant or prospective tenant, together with, in each case, actual attorneys’ fees and costs.
Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.
Rentable Area of the Premises The term "Rentable Area of the Premises" shall mean 7,000 square feet, which Landlord and Tenant have stipulated as the Rentable Area of the Premises. Tenant acknowledges that the Rentable Area of the Premises includes the usable area of the premises, without deduction for columns or projections, multiplied by a load factor to reflect a share of certain areas, which may include lobbies, corridors, mechanical, utility, janitorial, boiler and service rooms and closets, restrooms and other public, common and service areas of the Building.
Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Acceptance of the Premises By entry and taking possession of the -------------------------- Premises pursuant to this Lease, Tenant accepts the Premises as being in good and sanitary order, condition and repair and accepts the Premises in their condition existing as of the date of such entry, and Tenant further accepts the tenant improvements to be constructed by Landlord, if any, as being completed in accordance with the plans and specifications for such improvements, except for punch list items. Tenant acknowledges that neither Landlord nor Landlord's agents has made any representation or warranty as to the suitability of the Premises to the conduct of Tenant's business. Any agreements, warranties or representations not expressly contained herein shall in no way bind either Landlord or Tenant, and Landlord and Tenant expressly waive all claims for damages by reason of any statement, representation, warranty, promise or agreement, if any, not contained in this Lease. This Lease constitutes the entire understanding between the parties hereto and no addition to, or modification of, any term or provision of this Lease shall be effective until set forth in a writing signed by both Landlord and Tenant.
Leased Premises Lessor hereby leases to Lessee, and Lessee leases and takes from Lessor, the Leased Premises subject to the conditions of this Lease.
The Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto, and an outline of the Project is set forth in Exhibit A-1 attached hereto. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease, Tenant shall accept the Premises in its presently existing “as-is” condition and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant’s business, except as specifically set forth in this Lease. However, notwithstanding the foregoing, Landlord agrees that base Building electrical, mechanical, heating, ventilation and air conditioning and plumbing systems located in the Premises shall be in good working order and the roof shall be water tight as of the date Landlord delivers possession of the Premises to Tenant. Except to the extent caused by the acts or omissions of Tenant or any Tenant Parties (as defined in Section 10.13 below) by any alterations or improvements performed by or on behalf of Tenant, if such systems and/or the roof are not in good working order as of the date possession of the Premises is delivered to Tenant and Tenant provides Landlord with notice of the same within ninety (90) days following the date Landlord delivers possession of the Premises to Tenant, Landlord shall be responsible for repairing or restoring the same at Landlord’s sole cost and expense. Subject to any repairs or restoration required by the immediately preceding sentence, the commencement of business operations from the Premises by Tenant shall presumptively establish that the Premises and the Building were at such time in good and sanitary order, condition and repair. For purposes of Section 1938 of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges, that the Premises, the Building and the Project have not undergone inspection by a Certified Access Specialist (CASp).
Use of the Premises The Premises shall be used exclusively for the purpose ------------------- of research and development, storage, distribution, offices and marketing of medical devices. Lessee shall not use or permit the Premises, or any part thereof, to be used for any purpose or purposes other than the purpose for which the Premises are hereby leased; and no use shall be made or permitted to be made of the Premises, nor acts done, which will increase the existing rate of insurance upon the building in which the Premises are located, or cause a cancellation of any insurance policy covering said building, or any part thereof, nor shall Lessee sell or permit to be kept, used, or sold, in or about the Premises, any article which may be prohibited by the standard form of fire insurance policies. Lessee shall not commit or suffer to be committed any waste upon the Premises or any public or private nuisance or other act or thing which may disturb the quiet enjoyment of any other tenant in the building in which the premises are located; nor, without limiting the generality of the foregoing, shall Lessee allow the Premises to be used for any improper, immoral, unlawful, or objectionable purpose. Lessee shall not place any harmful liquids in the drainage system of the Premises or of the building of which the Premises form a part. No waste materials or refuse shall be dumped upon or permitted to remain upon any part of the Premises outside of the building proper except in trash containers placed inside exterior enclosures designated for that purpose by Lessor, or inside the building proper where designated by Lessor. No materials, supplies, equipment, finished or semi-finished products, raw materials, or articles of any nature shall be stored upon or permitted to remain on any portion of the Premises outside of the building proper. Lessee shall comply with all the covenants, conditions, and/or restrictions ("C.C. & R.'s") affecting the Premises
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
