Vendor’s Resellers as Related to This Agreement Vendor’s Named Resellers (“Resellers”) under this Agreement shall comply with all terms and conditions of this agreement and all addenda or incorporated documents. All actions related to sales by Authorized Vendor’s Resellers under this Agreement are the responsibility of the awarded Vendor. If Resellers fail to report sales to TIPS under your Agreement, the awarded Vendor is responsible for their contractual failures and shall be billed for the fees. The awarded Vendor may then recover the fees from their named reseller. Support Requirements If there is a dispute between the awarded Vendor and TIPS Member, TIPS or its representatives may, at TIPS sole discretion, assist in conflict resolution if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded Vendor’s TIPS project files, documentation and correspondence related to the requesting TIPS Member’s order. If there are confidentiality requirements by either party, TIPS shall comply to the extent permitted by law. Incorporation of Solicitation The TIPS Solicitation which resulted in this Vendor Agreement, whether a Request for Proposals, the Request for Competitive Sealed Proposals or Request for Qualifications solicitation, or other, the Vendor’s response to same and all associated documents and forms made part of the solicitation process, including any addenda, are hereby incorporated by reference into this Agreement as if copied verbatim. SECTION HEADERS OR TITLES THE SECTON HEADERS OR TITLES WITHIN THIS DOCUMENT ARE MERELY GUIDES FOR CONVENIENCE AND ARE NOT FOR CLASSIFICATION OR LIMITING OF THE RESPONSIBILITES OF THE PARTIES TO THIS DOCUMENT. STATUTORY REQUIREMENTS Texas governmental entities are prohibited from doing business with companies that fail to certify to this condition as required by Texas Government Code Sec. 2270. By executing this agreement, you certify that you are authorized to bind the undersigned Vendor and that your company (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. You certify that your company is not listed on and does not and will not do business with companies that are on the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf You certify that if the certified statements above become untrue at any time during the life of this Agreement that the Vendor will notify TIPS within three (3) business day of the change by a letter on Vendor’s letterhead from and signed by an authorized representative of the Vendor stating the non-compliance decision and the TIPS Agreement number and description at: Attention: General Counsel ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx, XX,00000 And by an email sent to xxxx@xxxx-xxx.xxx Insurance Requirements The undersigned Vendor agrees to maintain the below minimum insurance requirements for TIPS Contract Holders: General Liability $1,000,000 each Occurrence/ Aggregate Automobile Liability $300,000 Includes owned, hired & non-owned Workers' Compensation Statutory limits for the jurisdiction in which the Vendor performs under this Agreement. Umbrella Liability $1,000,000 When the Vendor or its subcontractors are liable for any damages or claims, the Vendor’s policy, when the Vendor is responsible for the claim, must be primary over any other valid and collectible insurance carried by the Member. Any immunity available to TIPS or TIPS Members shall not be used as a defense by the contractor's insurance policy. The coverages and limits are to be considered minimum requirements and in no way limit the liability of the Vendor(s). Insurance shall be written by a carrier with an A-; VII or better rating in accordance with current A.M. Best Key Rating Guide. Only deductibles applicable to property damage are acceptable, unless proof of retention funds to cover said deductibles is provided. "Claims made" policies will not be accepted. Vendor’s required minimum coverage shall not be suspended, voided, cancelled, non-renewed or reduced in coverage or in limits unless replaced by a policy that provides the minimum required coverage except after thirty (30) days prior written notice by certified mail, return receipt requested has been given to TIPS or the TIPS Member if a project or pending delivery of an order is ongoing. Upon request, certified copies of all insurance policies shall be furnished to the TIPS or the TIPS Member. Special Terms and Conditions • Orders: All Vendor orders received from TIPS Members must be emailed to TIPS at tipspo@tips- xxx.xxx. Should a TIPS Member send an order directly to the Vendor, it is the Vendor’s responsibility to forward a copy of the order to TIPS at the email above within 3 business days and confirm its receipt with TIPS. • Vendor Encouraging Members to bypass TIPS agreement: Encouraging TIPS Members to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program. • Order Confirmation: All TIPS Member Agreement orders are approved daily by TIPS and sent to the Vendor. The Vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.
Breach by Authorized User An Authorized User’s breach shall not be deemed a breach of the Centralized Contract; rather, it shall be deemed a breach of the Authorized User’s performance under the terms and conditions of the Centralized Contract.
Complaints by Bidders and Handling of Complaints (ix) The Recipient shall implement an effective and independent protest mechanism allowing bidders to protest and to have their protests handled in a timely manner. Fraud and Corruption
Exclusive Negotiations The State will not bargain collectively or meet with any employee organization other than MSEA-SEIU with reference to terms and conditions of employment of employees covered by this Agreement. If any such organizations request meetings they will be advised by the State to transmit their requests concerning terms and conditions of employment to MSEA-SEIU.
Defendant’s Breach of Plea Agreement If the defendant commits any crimes, violates any conditions of release, or violates any term of this plea agreement between the signing of this plea agreement and the date of sentencing, or fails to appear for sentencing, or if the defendant provides information to the Probation Office or the Court that is intentionally misleading, incomplete, or untruthful, or otherwise breaches this plea agreement, the United States will be released from its obligations under this agreement. The defendant, however, will remain bound by the terms of the agreement, and will not be allowed to withdraw his plea of guilty. The defendant also understands and agrees that in the event he violates this plea agreement, all statements made by him to law enforcement agents subsequent to the execution of this plea agreement, any testimony given by him before a grand jury or any tribunal or any leads from such statements or testimony shall be admissible against him in any and all criminal proceedings. The defendant waives any rights that he might assert under the United States Constitution, any statute, Rule 11(f) of the Federal Rules of Criminal Procedure, Rule 410 of the Federal Rules of Evidence, or any other federal rule that pertains to the admissibility of any statements made by him subsequent to this plea agreement.
Supplier A manufacturer, fabricator, distributor, supplier, or vendor of goods or equipment in connection with the Work, or any other party having a Contract or Purchase Order with the Contractor or with a Subcontractor to furnish materials or equipment to be incorporated in the Work by the Contractor or a Subcontractor.
Product Warranties Except as set forth in Schedule 3.15, (a) there are no warranties express or implied, written or oral, with respect to the Business and (b) there are no pending or threatened claims with respect to any such warranty, and Seller has no liability with respect to any such warranty, whether known or unknown, absolute, accrued, contingent or otherwise and whether due or to become due.
STATE’S ABILITY TO MODIFY SCOPE OF MASTER CONTRACT Subject to mutual agreement between the parties, Enterprise Services reserves the right to modify the goods and/or services included in this Master Contract; Provided, however, that any such modification shall be effective only upon thirty (30) days advance written notice; and Provided further, that any such modification must be within the scope of this Master Contract.
Supplier Warranties The Supplier represents and warrants that:
The Supplier Service Provider remains liable for its contractual obligations under the Agreement, including all services rendered by the sub-contractor.
