Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Commencement Date The Subcontractor shall be permitted to begin the Services on , 20 (“Commencement Date”).
Term of Lease This Lease shall commence on the date of ________ and shall continue until its natural termination under this part on the date of ________ at 11:59 PM. After the date of termination, this Lease shall automatically renew and shall continue for the same term amount until Landlord or Tenant undertake cancellation of this Lease in writing. At the expiration of this Lease, Tenant shall be responsible for providing a forwarding address to Landlord to receive any funds owed or other notices.
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Access to Leased Premises Landlord may enter the Leased Premises after business hours, upon twenty-four (24) hour notice to Tenant (and at any time and without notice in case of emergency), for the purposes of (a) inspect the Leased Premises, (b) exhibiting the Leased Premises to prospective purchasers, lenders or, within one hundred eighty (180) days of the end of the Term, prospective, (c) determining whether Tenant is complying with all of its obligations hereunder, (d) supplying janitorial service and any other services to be provided by Landlord to Tenant hereunder, (e) post notices of non-responsibility, and (f) make repairs required of Landlord under the terms hereof or repairs to any adjoining space or utility services or make repairs, alterations or improvements to any other portion of the Building. For such purposes, Landlord shall at all times have and retain a key with which to unlock all of the doors in, on or about the Leased Premises (excluding Tenant’s vaults, safes, storage facilities for sensitive materials, confidential patient files and similar areas designated in writing by Tenant in advance); and Landlord shall have the right to use any and all means which Landlord may deem proper to open said doors in any emergency in order to obtain entry to the Leased Premises. If, as a result of any such inspection or for any reason, Landlord reasonably determines that Tenant has failed to meet its obligations under Section 5.2 hereof, Landlord shall so notify Tenant and Tenant shall immediately commence to cure any such failure. In the event Tenant refuses or neglects to commence and complete such cure within a reasonable time, Landlord may make or cause to be made such repairs. In such event, Landlord’s cost to make such repairs shall constitute an Advance.
Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.
Agreement to Lease Landlord agrees to lease to Tenant and Tenant agrees to lease from Landlord, according to the terms and conditions set forth herein, the Premises.
Lease Agreement On the terms stated in this Lease, Landlord leases the Premises to Tenant, and Tenant leases the Premises from Landlord, for the Term beginning on the Commencement Date and ending on the Termination Date unless extended or sooner terminated pursuant to this Lease.
Right to Lease Landlord reserves the absolute right to effect such other tenancies in the Project as Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Building or Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants shall, during the Lease Term, occupy any space in the Building or Project.
