Fiduciary Damages Sample Clauses

Fiduciary Damages. Fiduciary Damages shall include damages awarded by a court of competent jurisdiction to a Participant arising from or due to the PACE's arbitrary, capricious, or other behavior constituting a breach of its fiduciary duty. As such, The Phia Group, when acting as the PACE and a fiduciary in that limited role, shall indemnify Client: (1) only to the extent that the liability underlying a final judgment or award is determined to be the direct consequence of arbitrary or capricious conduct, intentional wrongdoing, bad faith, criminal conduct or fraud that is solely attributable to The Phia Group; and (2) only if Client incur(s) losses that it would not have incurred but-for such conduct by The Phia Group. Fiduciary Damages shall include all attorney's fees incurred by The Phia Group acting as the PACE, as well as those attorney's fees incurred by Client in connection with a Second Level Post-Service Final Appeal referred to the PACE for the purpose of issuing a Directive, if such attorneys are retained by The Phia Group and/or if a court of competent jurisdiction determines with finality that such fees and costs are to be paid by The Phia Group. Fiduciary Damages shall also include other fees, costs and expenses resulting from the investigation, adjudication, and defense of a Directive issued by the PACE.
Sample 1
AutoNDA by SimpleDocs

Related to Fiduciary Damages

  • Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.

  • Direct Damages A PARTY’S DAMAGES RESULTING FROM A BREACH OR VIOLATION OF ANY REPRESENTATION, WARRANTY, COVENANT, AGREEMENT OR CONDITION CONTAINED IN THIS AGREEMENT OR ANY ACT OR OMISSION ARISING FROM OR RELATED TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DIRECT DAMAGES AND SHALL NOT INCLUDE ANY OTHER LOSS OR DAMAGE, INCLUDING INDIRECT, SPECIAL, CONSEQUENTIAL, INCIDENTAL, EXEMPLARY OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, PRODUCTION, OR REVENUES, AND EACH PARTY RELEASES THE OTHER PARTY FROM ALL SUCH CLAIMS FOR LOSS OR DAMAGE OTHER THAN ACTUAL DIRECT DAMAGES; PROVIDED THAT THIS LIMITATION TO DIRECT DAMAGES SHALL NOT LIMIT THE PARTIES’ INDEMNIFICATION OBLIGATIONS UNDER Section 3.5(c), Section 7.3, AND Article 15.

  • Indirect Damages To the maximum extent permitted by Law, the Stripe Parties will not be liable to you or your Affiliates in relation to this Agreement or the Services during and after the Term (whether in contract, negligence, strict liability or tort, or on other legal or equitable grounds) for any lost profits, personal injury, property damage, loss of data, business interruption, indirect, incidental, consequential, exemplary, special, reliance, or punitive damages, even if these losses, damages, or costs are foreseeable, and whether or not you or the Stripe Parties have been advised of their possibility.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the bidder hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Special Damages NOTWITHSTANDING ANY OTHER PROVISION OF THIS AGREEMENT TO THE CONTRARY, AND EXCEPT AS PROVIDED BELOW, IN NO EVENT WILL EITHER PARTY OR ANY PERSON IN ITS GROUP BE LIABLE FOR SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS SUFFERED BY AN INDEMNITEE, HOWEVER CAUSED AND ON ANY THEORY OF LIABILITY, IN CONNECTION WITH ANY DAMAGES ARISING HEREUNDER OR THEREUNDER; PROVIDED, HOWEVER, THAT TO THE EXTENT AN INDEMNIFIED PARTY IS REQUIRED TO PAY ANY DAMAGES, INCLUDING SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS (OTHER THAN DAMAGES OR LOST PROFITS CONSTITUTING EXCLUDED LIABILITIES), TO A PERSON WHO IS NOT IN EITHER GROUP IN CONNECTION WITH A THIRD PARTY CLAIM, SUCH DAMAGES WILL CONSTITUTE DIRECT DAMAGES AND WILL NOT BE SUBJECT TO THE LIMITATION SET FORTH IN THIS SECTION 11.17.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

Time is Money Join Law Insider Premium to draft better contracts faster.