Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.
Up-Front Payment Connetics shall issue to Genentech upon the Original Closing Date (as defined in the Stock Agreement) shares of Connetics Common Stock (“Original Issuance Shares” as defined in the Stock Agreement) with a fair market value equal to two million dollars ($2,000,000), on the terms and conditions set forth in the Stock Agreement. If, on the Second Closing Date (as defined in the Stock Agreement), the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price (as defined in the Stock Agreement)) is less than four million dollars ($4,000,000), Connetics shall issue to Genentech upon the Second Closing Date the number of additional shares of Connetics Common Stock (the “Second Issuance Shares,” as defined in the Stock Agreement) equal to the lesser of: (i) the number of shares necessary to increase the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price) plus the Second Issuance Shares (based on the Second Issuance Price) to four million dollars ($4,000,000) or (ii) the number of shares necessary to increase the aggregate number of the Company’s shares of Common Stock held by Genentech (exclusive of any shares that Genentech has purchased from parties other than the Company) to 9.9% of the Company’s total outstanding shares of Common Stock as of the close of business on the third trading day before the Second Closing Date, on the terms and conditions set forth in the Stock Agreement. In lieu of all or any portion of the Second Issuance Shares that the Company is obligated to issue to Genentech on the Second Closing Date, the Company may elect to pay Genentech the cash value of such Second Issuance Shares (based on the Second Issuance Price). The Original Closing and the Second Closing of the stock issuances shall take place as described in the Stock Agreement. In the event that Connetics does not issue to Genentech all of the Second Issuance Shares or the cash value of the Second Issuance Shares, Genentech may, in addition to other remedies available to it by law or in equity, immediately terminate this Agreement and the licenses granted to Connetics hereunder. Such termination by Genentech of the Agreement and the licenses hereunder does not discharge Connetics’ obligation to issue all of the Second Issuance Shares or to pay to Genentech the cash value of the Second Issuance Shares. The up-front payment shall not be creditable against any royalty payments owed by Connetics under Sections 8.3 and 8.4 below.
Earn-Out Payment As part of the Consideration, the Acquirer shall cause the REIT to pay to the Contributor (or its designee), within sixty (60) days after the "Calculation Date" (as defined below), an amount equal to the Earn-Out Payment (as calculated below); provided, however, that the amount of the Earn-Out Payment shall not exceed $1,800,000. If during the period beginning on the date on which the Project is open for business and available for use by paying overnight guests and ending on the date which is thirty-six (36) full calendar months after the last day of the month in which such opening date occurs (the "Calculation Date") the cumulative "Operating Profit" for the Project (as that term is defined in that certain Management Agreement to be entered into as of Closing (the "Management Agreement") between the TRS Affiliate (as defined below) and Crestline Hotels & Resorts, Inc.) is more than $9,500,000, then the Earn-Out Payment shall be equal to fifty percent (50%) of the difference between (a) the actual amount of the cumulative Operating Profit (as of the Calculation Date) for such 3-year period, and (b) $9,500,000. In the event the cumulative Operating Profit for such 3-year period is $9,500,000 or less, then no Earn-Out Payment shall be payable. If the Contributor is entitled to the Earn-Out Payment pursuant to this Section 1.3, then the Contributor (or its designee) shall receive the Earn-Out Payment in the form of Units, provided the Contributor (or its designee) continues to be an "accredited investor" as described herein. The number of Units delivered to the Contributor (or its designee) shall be equal to the calculated amount of the Earn-Out Payment divided by the average closing price per Common Share of the REIT for the twenty (20) trading days immediately preceding the Calculation Date.
Distribution Assistance Fees (Asset-Based Sales Charge) Payments In its sole discretion and irrespective of whichever alternative method of making service fee payments to Recipients is selected by the Distributor, in addition the Distributor may make distribution assistance fee payments to a Recipient quarterly, or at such other interval as deemed appropriate by the Distributor, within forty-five (45) days after the end of each calendar quarter or other period, at a rate not to exceed 0.1875% (0.75% on an annual basis) of the average during the period of the aggregate net asset value of Shares computed as of the close of each business day constituting Qualified Holdings owned beneficially or of record by the Recipient or its Customers until such Shares are redeemed or converted to another class of shares of the Fund, provided, however, that a majority of the Independent Trustees may, but are not obligated to, set a time period (the "Recipient Maximum Holding Period") for making such payments. Distribution assistance fee payments shall be made only to Recipients that are registered with the SEC as a broker-dealer or are exempt from registration. The distribution assistance to be rendered by the Recipients in connection with the sale of Shares may include, but shall not be limited to, the following: distributing sales literature and prospectuses other than those furnished to current Shareholders, providing compensation to and paying expenses of personnel of the Recipient who support the distribution of Shares by the Recipient, and providing such other information and services in connection with the distribution of Shares as the Distributor or the Fund may reasonably request.
PREMIUM PAYMENT METHOD The Bank shall pay an amount equal to the planned premiums and any other premium payments that might become necessary to keep the policy in force.
Earn-Out Payments (i) Promptly, but in any event within five (5) Business Days, after the Escrow Agent’s receipt of joint written instructions (“Earn-Out Payment Instructions”) from the DT Representative (on behalf of Purchaser) and the Seller Representative that for any Earn-Out Year there has been a final determination in accordance with Section 2.2 of the Share Exchange Agreement (but subject to Sections 2.4 and 2.5 of the Share Exchange Agreement) with respect to the Earn-Out Payment for such Earn-Out Year or the Alternative Earn-Out Payment (the date that the Escrow Agent receives Earn-Out Payment Instructions with respect to any Earn-Out Year, an “Earn-Out Release Date”), the Escrow Agent shall distribute Escrow Property from the Escrow Account in accordance with such Earn-Out Payment Instructions (A) to the Sellers in an amount equal to the Earn-Out Payment (excluding for the avoidance of doubt, the amount of any Accrued Dividends payable by the Purchaser separate from the Escrow Account) less the sum of (I) the Reserved Amount (as defined below) as of the date of such payment, and (II) the amount of any Indemnification Claims that have been paid from the Escrow Account prior to such time but have not previously been used to reduce the amount of any prior Earn-Out Payment (but net of any prior Earn-Out Payments that have not yet been paid and are still being retained in the Escrow Account as of such time for Indemnification Claims that are still Pending Claims as of such time), up to a maximum amount equal to such Earn-Out Payment, and (B), after the last Earn-Out Year only, to Purchaser any portion of any Earn-Out Payments that were not earned by the Sellers in accordance with the Share Exchange Agreement. For the determination of the Escrow Shares to be withheld for the Reserved Amount, the Escrow Shares shall be valued at the Purchaser Share Price as of the applicable Earn-Out Release Date.
