Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.
Liability for other losses, damages etc Save and except as expressly provided in this Article, neither Party hereto shall be liable in any manner whatsoever to the other Party in respect of any loss, damage, cost, expense, claims, demands and proceedings relating to or arising out of occurrence or existence of any Force Majeure Event.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Damages and Costs You agree to pay for damages, lost property or extraordinary service or administrative costs you, your designated roommate or your guests cause to University residence facilities whether through accident, neglect or intent. See Appendix II for more information about assessments. All residents of a floor or unit may be assessed for cleaning, damages, lost property or extraordinary service costs where the person(s) responsible cannot be ascertained by the University but where the damages, lost property, or excessive mess were reasonably believed by Student Housing and Hospitality Services to be caused by one or more residents of a floor or unit. Where charges and costs have not been paid by the specified date, a late fee will be added. Failure to pay assessments may result in the relocation of you or other resident(s) to another floor or unit, denial of future residence assignment or eviction from residence. To appeal an assessment you must follow the written appeal procedure outlined on the assessment form. Appeals will only be considered if you are not in arrears for any other fees, charges or amounts owed to Student Housing and Hospitality Services.
Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.
INDEMNIFICATION FOR DAMAGES, TAXES AND CONTRIBUTIONS CONTRACTOR shall exonerate, indemnify, defend, and hold harmless COUNTY (which for the purpose of paragraphs 5 and 6 shall include, without limitation, its officers, agents, employees and volunteers) from and against:
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
