POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
CONVEYANCE OF THE SAID APARTMENT The Promoter, on receipt of Total Price of the [Apartment/Plot] as per para 1.2 under the Agreement from the Allottee, shall execute a conveyance deed and convey the title of the [Apartment/Plot] together with proportionate indivisible share in the Common Areas within 3 months from the date of issuance of the occupancy certificate* and the completion certificate, as the case may be, to the allottee. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. However, in case the Allottee fails to deposit the stamp duty and/or registration charges within the period mentioned in the notice, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till payment of stamp duty and registration charges to the Promoter is made by the Allottee.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a two bedroom service apartment unit, intermediate lot bearing postal address of No. A-20-10, Xxxxxx A, Residensi Southkey Mozek, Persiaran Southkey Utama, Kota Xxxxxxxx, 00000 Xxxxx Xxxxx, Xxxxx. RESERVE PRICE: The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM486,000.00 (RINGGIT MALAYSIA FOUR HUNDRED AND EIGHTY SIX THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Xxxxxxx’s Order in favour of UOBM for CHOONG LIP PONG or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S CHUA & PARTNERS, of Suite 8-12A-6, Xxxxx 00X, Xxxxxx Xxxxxxx, Xx. 0, Xxxxx Xxxx Xxxxxx, 00000 Xxxxx Xxxxxx. (Ref No.: MHH/UOB/A924/22/ChoongLipPong, Tel No. 00-0000 0000 / 00-0000 0000, Fax No.: 00-0000 0000) solicitors for the Assignee herein or the undermentioned Auctioneer. EHSAN AUCTIONEERS SDN. BHD. (Co. No. 617309-U) DATO’ HAJI XXXXX XXXXX BIN X.X. XXXX (D.I.M.P) Xxxxx X-00-0X, Xxxxx 00, Xxxxx X, Xxxxx Xxxxxx II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 & 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: XXXXX/UOB0477/CP(2) Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx OR Unit Xx. 0.00, 0xx Xxxxx, Xxxxxx XXX, Xx. 0, Xxxxx Xxxx Xxxx Xxxxx, 80000 Johor Bahru, Johor. H/P EN JO: 012-742 1763 (Marketing) PERISYTIHARAN JUALAN DALAM PERKARA MENGENAI PERJANJIAN PINJAMAN XXX SURATIKATAN PENYERAHAN HAK KEDUA-DUANYA BERTARIKH 06HB SEPTEMBER, 2016 ANTARA UNITED OVERSEAS BANK (MALAYSIA) BHD [No. Pendaftaran: 199301017069/271809-K] PIHAK PEMEGANG SERAHHAK/BANK XXX XXXXXX LIP PONG (NO K/P.: 820721-01-5979) PIHAK PEMINJAM / PIHAK PENYERAHHAK Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Pinjaman xxx Suratikatan Penyerahan Hak Kedua-duanya bertarikh 06hb September, 2016 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah. AKAN MENJUAL HARTANAH YANG DIHURAIKAN DI BAWAH SECARA LELONGAN AWAM SECARA ATAS TALIAN PADA 11HB JANUARI 2023BERSAMAAN HARI RABU, JAM 3.00 PETANG, XX XXXXX WEB XXX.XXXXXXXXXXXXXXXX.XXX Bakal pembida boleh mengemukakan bida untuk hartanah dalam talian melalui xxx.xxxxxxxxxxxxxxxx.xxx (Untuk pembidaan dalam talian, xxxx daftar sekurang-kurangnya satu (1) hari bekerja sebelum hari lelong untuk tujuan pendaftaran & pengesahan) NOTA: Xxxxx-xxxxx pembeli adalah dinasihatkan agar membuat perkara-perkara yang berikut sebelum jualan lelong:-
CONVEYANCE OF THE SAID PLOT The Promoter, on receipt of Total Price of the [Apartment/Plot] as per para 1.2 under the Agreement from the Allottee, shall execute a conveyance deed and convey the title of the plot together with proportionate indivisible share in the Common Areas within 3 months from the date of issuance of the occupancy certificate* and the completion certificate, as the case may be, to the allottee. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. However, in case the Allottee fails to deposit the stamp duty and/or registration charges within the period mentioned in the notice, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till payment of stamp duty and registration charges to the Promoter is made by the Allottee.
POSSESSION OF THE PROPERTY The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.
CONSTRUCTION AND RENOVATION Construction of academic or residential buildings on the UC Berkeley campus may be scheduled for the term of this Lease in the vicinity of the apartments. Capital improvement and other major housing construction or repair projects will necessarily cause increased noise and dust in affected and nearby residences at certain times. There is the possibility of both planned and unplanned utility shutdowns and access to certain facilities, streets, parking lots, walking, and bike pathways may be limited, rerouted, or completely restricted. The University will work with building contractors to make every effort to minimize construction inconveniences. By agreeing to this Lease Agreement, the Resident acknowledges notice of the possibility of scheduled construction and access limitations, and acknowledges that there will be disturbances, disruptions, and inconveniences resulting from such constructions and has agreed to such. The Resident also acknowledges that increased noise, dust, potential reassignment, or loss of parking spaces related to construction or renovation are not grounds for cancellation or termination of this Lease.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
